ILLUMINATION HEALTH + HOME (FORMERLY ILLUMINATION FOUNDATION)

Home Browse Search

EXHIBIT 2 regardless of source of manufacture or construction;assign and schedule,work at their discretion; and (#} Assign overt!=,determine when it will be,worked and tine ournber mid identity of the employees engaged in such work, subject to such provisions in applicable Master Labor Agreenicnt(s)requiring such, assignments be equalized or otherwise made, in a.uoadisoriininatory manner. Section 9.2 Speciig City Right In addition to the following and other rights of the City emutorated in this Agreement,the City expressly reserves its management rights and all the rights conferred on it by law. The City's rights(arid thoso of the Contract Administrator on its behalf) include but are not limited to the right to; (a) Inspect any construction site or facility to ensure that the Contraotor fellows the, applicable safety and rather work requirements; (b) Require Contractors to establish a different work wools or shift schedule for particular employees as roquired to meet the operational n1mcls of the Project Work.at a particular location; (c) At its sole option, terminate, delay and/or suspend arty and all portions of the covered work at any time;prohibit some or all work on certain days or during curtain hours of the 1 day to accommodate the ongoing operations of the C ity's Facilities and/or to mitigate the efFect of l ongoing Project Work on businesses and residents in the neighborhood of the Project site; and/or require such other operational or schedule changes it deems necessary, in its sole,judgment, to e-ffectivoly maintain its primary mission and mrnain a good neighbor to those in the area of its facilities,(Ire order to permit the Contractors and Unions to make appropriate scheduling plans,the City will provide the CWA Administrator, and the affected Contractor's) and Union(s) with reasonable notice of any changes it requires pursuant to this section;provided, however, that if notice is not provided in time, to advise employees not to report for work, show-up pay shall be due pursuant to the provision of Article 6, Section 6.6); (d) Approve arty work imthods, procedures and techniques used by Contractors whether or not these methods,procedures or techniques are part of industry practices or customs; and (e) Investigate and process complaints, througli the CW.A Administrator, in the matter set forth tin Articles 7 and 10. I Section 9.3 l ofofMaterials "There should be no limitations or restriction by Union upon a Contractor's choice of materials or design, nor, regardless of source or location, upon the full use and utilization, of equipment, machinery, packaging, precast, prefabricated, preiinished, or preassembled materials,tools or other labor saving devices, subject to the application of the State Public Contracts and Labor Codes as required by law.The ousite installation or application of such items shall be performed by the craft having jurisdiction over such work. Community Workforce Agreement 22 City of Santa Ana City Council 16 --234 5/19/2026