25F - AGMT - 605-611 EAST WASHINGTON ST LOAN

Home Browse Search

terrorism; epidemics; quarantine restrictions; freight embargoes; lack of transportation; governmental restrictions or priority; litigation; unusually severe weather; inability to secure necessary labor, materials or tools, delays of any contractor, subcontractor or supplier; acts or omissions of the other party; acts or failures to act of the City, Agency, or any other public or governmental agency or entity (other than the acts or failures to act of the Agency or City which shall not excuse performance by the Agency or City). Notwithstanding anything to the contrary in this Agreement, an extension of time for any such cause shall be for the period of the enforced delay and shall commence to run from the time of the commencement of the cause, if notice by the party claiming such extension is sent to the other party within thirty (30) days of the commencement of the cause. Times of performance under this Agreement may also be extended in writing by the mutual agreement of Agency/City (through the Executive Director) and Developer. Notwithstanding any provision of this Agreement to the contrary, the lack of funding to complete the Improvements shall not constitute grounds of enforced delay pursuant to this Article 1700. 1800. INDEMNIFICATION 1801. Nonliability of Agency and City. Developer acknowledges and agrees that: (a) The relationship between Developer and Agency/City is and shall remain solely that of borrower and lender, Agency/City neither undertakes nor assumes any responsibility to review, inspect, supervise, approve (other than for aesthetics) or inform Developer of any matter in connection with the construction, including matters relating to: (i) the performance of the construction work, (ii) architects, contractors, subcontractors and materialmen, or the workmanship of or materials used by any of them,. or (iii) the progress of the construction; and Developer shall rely entirely on its own judgment with respect to such matters and acknowledges that any review, inspection, supervision, approval or information supplied to Developer by City in connection with such matters is solely for the protection of Agency/City and that neither Developer nor any third party is entitled to rely on it; (b) Notwithstanding any other provision of any Loan Document: (i) the Agency and City are not a partner, joint venture, alter-ego, manager, controlling person or other business associate or participant of any kind of Developer and Agency/City does not intend to ever assume any such status; (ii) Agency/City's activities in connection with the Loan(s) shall not be "outside the scope of the activities of a lender of money" within the meaning of California Civil Code Section 3434, as modified or recodified from time to time, and Agency/City does not intend to ever assume any responsibility to any person for the quality or safety of the Property or the Project; and (iii) Agency/City shall not be deemed responsible for or a participant in any acts, omissions or decisions of Developer; (c) Agency/City shall not be directly or indirectly liable or responsible for any loss or injury of any kind to any person or property resulting from any construction on, or occupancy or use of, the Property, whether arising from: (i) any defect in any building, grading, landscaping or other onsite or offsite improvement; (ii) any act or omission of Developer or any of Developer's agents, employees, independent contractors, licensees or invitees; or (iii) any accident on the Property or any fire or other casualty or hazard thereon; and (d) By accepting or approving anything required to be performed or given to Agency/City under the Loan Documents, including any certificate, financial statement, survey, appraisal or insurance policy, Agency/City shall not be deemed to have warranted or represented the 51 25F-57