The URL can be used to link to this page

Home My WebLink AboutLEED ELECTRIC, INC.INSURANCE ON FILE WORK MAY PROCEED UNTIL INSURANCE EXPIRES I O• �l • Ze? CLERK OF COUNCIL DATE: A-2022-025-02 � AGREEMENT TO PROVIDE ON -CALL ELECTRICAL REPAIR AND REHABILITATION SERVICES m G THIS AGREEMENT is made and entered into this 15th day of February 2022 by and between a LEED Electric, Inc., a California corporation ("Contractor"), and the City of Santa Ana, a charter city and municipal corporation organized and existing under the Constitution and laws of the State of California ("City"). �'. PwA(Arnw4t Feryiander) 2 RECITALS A. On October 14, 2021, the City issued Request for Proposal No. 21-122, by which it sought a qualified contractor to provide on -call electrical repair and rehabilitations services for the City's Public Works Agency. B. Contractor submitted a responsive proposal that was among those selected by the City. Contractor represents that it is able and willing to provide the services described in the scope of work that was included in RFP 21-122. C. In undertaking the performance of this Agreement, Contractor represents that it is knowledgeable in its field and that any services performed by Contractor under this Agreement will be performed in compliance with such standards as may reasonably be expected from a professional contracting firm in the field. NOW THEREFORE, in consideration of the mutual and respective promises, and subject to the terms and conditions hereinafter set forth, the parties agree as follows: 1. SCOPE OF SERVICES On an on -call basis, and at the City's sole discretion, Contractor shall perform the services described in the scope of work that was included in RFP No. 21-122, which is attached as Exhibit A and incorporated in full, and as further described in Contractor's Proposal, which is attached as Exhibit B and incorporated in full. 2. COMPENSATION a. City neither warrants nor guarantees any minimum or maximum compensation to Contractor under this Agreement. Contractor shall be paid only for actual services performed under this Agreement at the rates and charges identified in Exhibit B. Contractor is one of two (2) contractors selected to provide services on an on -call basis under RFP 21-122. The total compensation for services provided by all contractors selected under RFP No. 21-122, including any extension period, shall not exceed the shared aggregate amount of six million dollars and zero cents (*000 000). b. Payment by City shall be made within forty-five (45) days following receipt of proper invoice evidencing work performed, subject to City accounting procedures. Page I of 10 Payment need not be made for work which fails to meet the standards of performance set forth in the Recitals and Scope of Work, which may reasonably be expected by City. 3. TERM This Agreement shall commence on February 15, 2022 and terminate on February 14, 2025, unless terminated earlier in accordance with Section 17, below. The term of this Agreement may be extended for one (1) two (2) year period upon a writing executed by the City Manager and City Attorney. 4. PREVAILING WAGES Contractor is aware of the requirements of California Labor Code Section 1720, et seq., and 1770, et seq., as well as California Code of Regulations, Title 8, Section 16000, et seq., ("Prevailing Wage Laws"), which require the payment of prevailing wage rates and the performance of other requirements on "public works" and "maintenance" projects. If the services being performed are part of an applicable "public works" or "maintenance" project, as defined by the Prevailing Wage Laws, and the total compensation is $1,000 or more, Contractor agrees to fully comply with such Prevailing Wage Laws. Contractor shall defend, indemnify and hold the City, its elected officials, officers, employees and agents free and harmless from any claim or liability arising out of any failure or alleged failure to comply with the Prevailing Wage Laws. 5. INDEPENDENT CONTRACTOR Contractor shall, during the entire term of this Agreement, be construed to be an independent contractor and not an employee of the City. This Agreement is not intended nor shall it be construed to create an employer -employee relationship, a joint venture relationship, or to allow the City to exercise discretion or control over the professional manner in which Contractor performs the services which are the subject matter of this Agreement; however, the services to be provided by Contractor shall be provided in a manner consistent with all applicable standards and regulations governing such services. Contractor shall pay all salaries and wages, employer's social security taxes, unemployment insurance and similar taxes relating to employees and shall be responsible for all applicable withholding taxes. 6. OWNERSHIP OF MATERIALS This Agreement creates a non-exclusive and perpetual license for City to copy, use, modify, reuse, or sublicense any and all copyrights, designs, and other intellectual property embodied in plans, specifications, studies, drawings, estimates, and other documents or works of authorship fixed in any tangible medium of expression, including but not limited to, physical drawings or data magnetically or otherwise recorded on computer diskettes, which are prepared or caused to be prepared by Contractor under this Agreement ("Documents & Data"). Contractor shall require all subcontractors to agree in writing that City is granted a non-exclusive and perpetual license for any Documents & Data the subcontractor prepares under this Agreement. Contractor represents and warrants that Contractor has the legal right to license any and all Page 2 of 10 Documents & Data. Contractor makes no such representation and warranty in regard to Documents & Data which were provided to Contractor by the City. City shall not be limited in any way in its use of the Documents and Data at any time, provided that any such use not within the purposes intended by this Agreement shall be at City's sole risk. INSURANCE Prior to undertaking performance of work under this Agreement, Contractor shall maintain and shall require its subcontractors, if any, to obtain and maintain insurance as described below: a. Minimum Scope and Limit of Insurance 1. Commercial General Liability (CGL): Insurance Services Office Form CG 00 01 covering CGL on an "occurrence" basis, including products and completed operations, property damage, bodily injury and personal & advertising injury with limits no less than $2,000,000 per occurrence. If a general aggregate limit applies, either the general aggregate limit shall apply separately to this project/location (ISO CG 25 03 or 25 04) or the general aggregate limit shall be twice the required occurrence limit. 2. Automobile Liability: ISO Form Number CA 00 01 covering any auto (Code 1), or if Contractor has no owned autos, hired, (Code 8) and non -owned autos (Code 9), with a limit no less than $1,000,000 per accident for bodily injury and property damage. 3. Workers' Compensation: as required by the State of California, with Statutory Limits, and Employer's Liability Insurance with limit of no less than $1,000,000 per accident for bodily injury or disease. 4. If Contractor is or employs a licensed professional such as an architect or engineer: Professional liability (errors and omissions) insurance, with a combined single limit of not less than $2,000,000 per claim with $2,000,000 in the aggregate. If the Contractor maintains broader coverage and/or higher limits than the minimums shown above, the Cityquires and shall be entitled to the broader coverage and/or the higher limits maintained by the Contractor. Any available insurance proceeds in excess of the specified minimum limits of insurance and coverage shall be available to the City. b. Other. Insurance Provisions Additional Insured Status: The City, its officers, officials, employees, and volunteers are to be covered as additional insureds on the CGL policy with respect to liability arising out of work or operations performed by or on behalf of the Contractor including materials, parts, or equipment furnished in connectionwith such Page 3 of 10 work or operations. General liability coverage can be provided in the form of an endorsement to the Contractor's insurance (at least as broad as ISO Form CG 20 10 11 85 or if notavailable, through the addition of both CG 20 10, CG 20 26, CG 20 33, or CG 20 38; and CG 2037 if a later edition is used). 2. Primary Coverage: For any claims related to this contract, the Contractor's insurance coverage shall be primary coverage at least as broad as ISO CG 20 01 04 13 as respects the City, its officers, officials, employees, and volunteers. Any insurance or self- insurance maintained by the City, its officers, officials, employees, or volunteers shall be excess of the Contractor's insurance and shall not contribute with it. 3. Notice of Cancellation: Each insurance policy required above shall provide that coverage shall not be canceled, except with notice to the City. 4. Waiver of Subrogation: Contractor hereby grants to City a waiver of any right to subrogation that any insurer of said Contractor may acquire against the City by virtue of the payment of any loss under such insurance. Contractor agrees to obtain any endorsement that may be necessary to affect this waiver of subrogation, but this provision applies regardless of whether or not the City has received a waiver of subrogation endorsement from the insurer. Self -Insured Retentions: Self -insured retentions must be declared to and approved by the City. The City may require theContractor to purchase coverage with a lower retention or provide proof of ability to pay losses and related investigations, claim administration, and defense expenses within the retention. The policy language shall provide, or be endorsed to provide, that the self -insured retention may be satisfied by either the named insured or City. 6. Acceptability of Insurers: Insurance is to be placed with insurers authorized to conduct business in the state with a current A.M. Best's rating of no less than A:VII, unless otherwise acceptable to the City. 7. Claims Made Policies (applicable only to professional liability): i. The Retroactive Date must be shown, and must be before the date of the contract or the beginning of contract work. ii. Insurance must be maintained and evidence of insurance must be provided for at least five (5) years after completion of the contract of work. Page 4 of 10 iii. If coverage is canceled or non -renewed, and not replaced with another claims -made policy form with a Retroactive Date prior to the contract effective date, the Contractor must purchase "extended reporting" coverage for a minimum of five (5) years after completion of work. 8. Verification of Coverage: Contractor shall furnish the City with original Certificates of Insurance including all required amendatory endorsements (or copies of the applicable policy language effecting coverage requiredby this clause) and a copy of the Declarations and Endorsement Page of the CGL policy listing allpolicy endorsements to City before work begins. However, failure to obtain the required documents prior to the work beginning shall not waive the Contractor's obligation to provide them. The City reserves the right to require complete, certified copies of all required insurance policies, including endorsements required by these specifications, at any time. 9. Subcontractors: Contractor shall require and verify that all subcontractors maintain insurance meeting all the requirements stated herein, and Contractor shall ensure that City is an additional insured on insurance required from subcontractors. 10. Special Risks or Circumstances: City reserves the right to modify these requirements, including limits, based on the nature of therisk, prior experience, insurer, coverage, or other special circumstances. 8. INDEMNIFICATION Contractor agrees to defend, and shall indemnify and hold harmless the City, its officers, agents, employees, contractors, special counsel, and representatives from liability: (1) for personal injury, damages, just compensation, restitution, judicial or equitable relief arising out of claims for personal injury, including death, and claims for property damage, which may arise from the negligent operations of the Contractor or its subcontractors, agents, employees, or other persons acting on their behalf which relates to the services described in section 1 of this Agreement; and (2) from any claim that personal injury, damages, just compensation, restitution, judicial or equitable relief is due by reason of the terms of or effects arising from this Agreement. This indemnity and hold harmless agreement applies to all claims for damages, just compensation, restitution, judicial or equitable relief suffered, or alleged to have been suffered, by reason of the events referred to in this Section or by reason of the terms of, or effects, arising from this Agreement. The Contractor further agrees to indemnify, hold harmless, and pay all costs for the defense of the City, including fees and costs for special counsel to be selected by the City, regarding any action by a third party challenging the validity of this Agreement, or asserting that personal injury, damages,just compensation, restitution, judicial or equitable relief due to personal or property rights arises by reason of the terms of, or effects arising from this Agreement. City may make all reasonable decisions with respect to its representation in any legal proceeding. Page 5 of 10 Notwithstanding the foregoing, to the extent Contractor's services are subject to Civil Code Section 2782.8, the above indemnity shall be limited, to the extent required by Civil Code Section 2782.8, to claims that arise of, pertain to, or relate to the negligence, recklessness, or willful misconduct of the Contractor. 9. INTELLECTUAL PROPERTY INDEMNIFICATION Contractor shall defend, indemnify and hold harmless the City, its officers, agents, representatives, and employees against any and all liability, including costs, and attorney's fees, for infringement of any United States' letters patent, trademark, or copyright contained in the work product or documents provided by Contractor to the City pursuant to this Agreement. 10. RECORDS Contractor shall keep records and invoices in connection with the work to be performed under this Agreement. Contractor shall maintain complete and accurate records with respect to the costs incurred under this Agreement and any services, expenditures, and disbursements charged to the City for a minimum period of three (3) years, or for any longer period required by law, from the date of final payment to Contractor under this Agreement. All such records and invoices shall be clearly identifiable. Contractor shall allow a representative of the City to examine, audit, and make transcripts or copies of such records and any other documents created pursuant to this Agreement during regular business hours. Contractor shall allow inspection of all work, data, documents, proceedings, and activities related to this Agreement for a period of three (3) years from the date of final payment to Contractor tinder this Agreement. 11. CONFIDENTIALITY If Contractor receives from the City information which due to the nature of such information is reasonably understood to be confidential and/or proprietary, Contractor agrees that it shall not use or disclose such information except in the performance of this Agreement, and further agrees to exercise the same degree of care it uses to protect its own information of like importance, but in no event less than reasonable care. "Confidential Information" shall include all nonpublic information. Confidential information includes not only written information, but also information transferred orally, visually, electronically, or by other means. Confidential information disclosed to either party by any subsidiary and/or agent of the other party is covered by this Agreement. The foregoing obligations of non-use and nondisclosure shall not apply to any information that (a) has been disclosed in publicly available sources; (b) is, through no fault of the Contractor disclosed in a publicly available source; (c) is in rightful possession of the Contractor without an obligation of confidentiality; (d) is required to be disclosed by operation of law; or (e) is independently developed by the Contractor without reference to information disclosed by the City. 12. CONFLICT OF INTEREST CLAUSE Contractor covenants that it presently has no interest and shall not have interests, direct or indirect, which would conflict in any manner with performance of services specified under this Page 6 of 10 Agreement. 13. NOTICE Any notice, tender, demand, delivery, or other communication pursuant to this Agreement shall be in writing and shall be deemed to be properly given if delivered in person or mailed by first class or certified mail, postage prepaid, or sent by fax or other telegraphic communication in the manner provided in this Section, to the following persons: To City: Clerk of the City Council City of Santa Ana 20 Civic Center Plaza (M-30) P.O. Box 1988 Santa Ana, CA 92702-1988 Fax 714- 647-6956 Executive Director Public Works Agency City of Santa Ana 20 Civic Center Plaza (M-21) P.O. Box 1988 Santa Ana, CA 92702 To Contractor: LEED Electric, Inc. 13138 Arctic Circle Santa Fe Springs, CA 90670 Attn: Seyed J'amali, CEO A party may change its address by giving notice in writing to the other party. Thereafter, any communication shall be addressed and transmitted to the new address. If sent by mail, communication shall be effective or deemed to have been given three (3) days after it has been deposited in the United States mail, duly registered or certified, with postage prepaid, and addressed as set forth above. If sent by fax, communication shall be effective or deemed to have been given twenty-four (24) hours after the time set forth on the transmission report issued by the transmitting facsimile machine, addressed as set forth above. For purposes of calculating these timeframes, weekends, federal, state, County or City holidays shall be excluded. 14. EXCLUSIVITY AND AMENDMENT This Agreement represents the complete and exclusive statement between the City and Contractor regarding the subject matter herein, and supersedes any and all other agreements, oral or written, between the parties. In the event of a conflict between the terms of this Agreement and any attachments hereto, the terms of this Agreement shall prevail. This Agreement may not be modified except by written instrument signed by the City and by an authorized representative of Contractor. The parties agree that any terms or conditions of any purchase order or other instrument that are inconsistent with, or in addition to, the terms and conditions hereof, shall not bind or Page 7 of 10 obligate Contractor or the City. Each party to this Agreement acknowledges that no representations, inducements, promises or agreements, orally or otherwise, have been made by any party, or anyone acting on behalf of any party, which are not embodied herein. 15. ASSIGNMENT Inasmuch as this Agreement is intended to secure the specialized services of Contractor, Contractor may not assign, transfer, delegate, or subcontract any interest herein without the prior written consent of the City and any such assignment, transfer, delegation or subcontract without the City's prior written consent shall be considered null and void. Nothing in this Agreement shall be construed to limit the City's ability to have any of the services that are the subject to this Agreement performed by City personnel or by other contractors retained by City. 16. WAIVER No waiver of breach, failure of any condition, or any right or remedy contained in or granted by the provisions of this Agreement shall be effective unless it is in writing and signed by the party waiving the breach, failure, right or remedy. No waiver of any breach, failure or right, or remedy shall be deemed a waiver of any other breach, failure, right or remedy, whether or not similar, nor shall any waiver constitute a continuing waiver unless the writing so specifies. 17. TERMINATION This Agreement may be terminated by the City upon thirty (30) days written notice of termination. In such event, Contractor shall be entitled to receive and the City shall pay Contractor compensation for all services performed by Contractor prior to receipt of such notice of termination, subject to the following conditions: a. As a condition of such payment, the Executive Director may require Contractor to deliver to the City all work product completed as of such date, and in such case such work product shall be the property of the City unless prohibited by law, and Contractor consents to the City's use thereof for such purposes as the City deems appropriate. b. Payment need not be made for work that fails to meet the standard of performance specified in the Recitals of this Agreement. 18. NON-DISCRIMINATION Contractor shall not discriminate because of race, color, creed, religion, sex, marital status, sexual orientation, gender identity, gender expression, gender, medical conditions, genetic information, or military and veteran status, age, national origin, ancestry, or disability, as defined and prohibited by applicable law, in the recruitment, selection, teaching, training, utilization, promotion, termination or other employment related activities or any services provided under this Agreement. Contractor affirms that it is an equal opportunity employer and shall comply with all applicable federal, state and local laws and regulations. Page 8 of 10 A-2022-025-02 19. JURISDICTION -VENUE This Agreement has been executed and delivered in the State of California and the validity, interpretation, performance, and enforcement of any of the clauses of this Agreement shall be determined and governed by the laws of the State of California. Both parties further agree that Orange County, California, shall be the venue for any action or proceeding that may be brought or arise out of, in connection with or by reason of this Agreement. 20. PROFESSIONAL LICENSES Contractor shall, throughout the term of this Agreement, maintain all necessary licenses, permits, approvals, waivers, and exemptions necessary for the provision of the services hereunder and required by the laws and regulations of the United States, the State of California, the City of Santa Ana and all other governmental agencies. Contractor shall notify the City immediately and in writing of its inability to obtain or maintain such permits, licenses, approvals, waivers, and exemptions. Said inability shall be cause for termination of this Agreement. 21. MISCELLANEOUS PROVISIONS a. Each undersigned represents and warrants that its signature herein below has the power, authority and right to bind their respective parties to each of the terms of this Agreement, and shall indemnify City fully, including reasonable costs and attorney's fees, for any injuries or damages to City in the event that such authority or power is not, in fact, held by the signatory or is withdrawn. b. All exhibits referenced herein and attached hereto shall be incorporated as if fully set forth in the body of this Agreement. IN WITNESS WHEREOF, the parties hereto have executed this Agreement the date and year first above written. ATTEST: CITY OF SANTA ANA Daisy Gomez Kristine Ridge `. Clerk of the Council City Manager [signatures continued on next page] Page 9 of 10 APPROVED AS TO FORM SONIA R. CARVALHO City Attorney By: randon Salvatier a Deputy City Attorney RECOMMENDED FOR APPROVAL �Nabil Saba, PE Executive Director Public Works Agency LEED ELECTRIC, INC. Name: Seyed A. Jamali-Dinan Title: CEO Page 10 of 10 EXHIBIT A CITY OF SANTA ANA RFP NO.: 21-122 ON -CALL ELECTRICAL REPAIR AND REHABILITATION SERVICES Appendix ATTACHMENT 1: SCOPE OF WORK City of Santa Ana RFP 21-122 On -Call Electrical Repair and Rehabilitation Services Page 13 CITY OF SANTA ANA RFP NO.: 21-122 ON -CALL ELECTRICAL REPAIR AND REHABILITATION SERVICES SCOPE OF WORK A. INTRODUCTION AND BACKGROUND The City of Santa Ana is located in the County of Orange in Southern California. The City encompasses 27.2 square miles and a population over 343,000 people. The City of Santa Ana Public Works Agency — Water Resources Division oversees and maintains the daily operations of the Water System and Sanitary Sewer System. The City of Santa Ana's water system is comprised of approximately 478 miles of water main, 45 MG of storage at five (5) sites, seven (7) MWD connections, 21 groundwater wells, seven (7) pump stations, four (4) pressure regulating stations and utilizes two (2) pressure zones. The City of Santa Ana Public Works Agency Water Resources Division is soliciting proposals from qualified industrial electrical firms to provide on -call electrical repair and rehabilitation services. The City intends to select and enter into agreements with up to three firms to provide the described services for an aggregate annual amount amongst all selected firms. B. CONTRACTOR RESPONSIBILITIES The City of Santa Ana invites proposals to establish multiple contracts with vendors for electrical maintenance, repair, and rehabilitation at the City's water and wastewater facilities. Qualified respondents will be expected to provide new electrical installations, as well as scheduled and unscheduled electrical maintenance and/or repairs on an "as needed" basis. The Contractor shall provide all labor, materials, services, and equipment necessary for the complete installation of electrical systems. All work shall be in accordance with applicable trade practices, workmanship, meet warranties and shall conform to all applicable laws, codes and regulations. Business hours are considered from 7:00 A.M. to 5:00 P.M. (Monday through Friday). Any time outside of business hours of operation may be considered after hours/weekends. All work will be scheduled upon confirmation of scope and cost and completed within the time agreed upon for each specific item of work. The Contractor may not begin work before receiving a written Notice to Proceed by the City's Project Manager. All services, equipment and materials provided by the Contractor must be in accordance with all applicable Federal, State and local regulations, laws, and codes such as the California Electric Code, California Building Code, and other applicable codes not listed. C. SCOPE OF SERVICES The Contractor shall provide all transportation, labor, materials and equipment necessary to repair, replace, and install existing and new electrical systems as required for the following types of facilities; Water Booster Stations, Sewer Lift Stations, Water Reservoir Sites, Pressure Control Stations, and Water Well Sites. The Contractor shall provide the following scope of services: City of Santa Ana RFP 21-122 On -Call Electrical Repair and Rehabilitation Services Page 14 CITY OF SANTA ANA RFP NO.: 21-122 ON -CALL ELECTRICAL REPAIR AND REHABILITATION SERVICES 1. ELECTRICAL SERVICES The Contractor shall be able to perform, but are not limited to, the following electrical services: • Repair or replacement of motor control stations (up to 480 volts) • Repair or replacement of exterior wiring, interior wiring, conduit, solid state soft starters, variable -frequency drives (VFD), motor controls and motor control centers (MCC), switch gears, fuses, electrical circuit boxes, transformers, programmable logic controllers (PLCs), etc. • Trouble shooting of existing electrical wiring and appurtenances (electrical testing) • New installations of electrical wiring and appurtenances • Telecommunication installations • Instrumentation installations and fiber connections (not including programming) • Technical electrician support to City Staff as requested • Lighting installations • Electrical distribution and control equipment installations (underground distribution conduit, cables, and pull boxes) • Poles, pole foundations and concrete work installations and excavations • Excavations, backfilling and compaction for trenches and pull boxes • Branch circuit panels and wiring installations • Shop and record drawings, material submittals: and work schedules 2. PERFORMANCE TESTS When requested by the City and upon completion of electrical installation, the Contractor shall test and demonstrate that the system operates in accordance with the Drawings and Specifications. Performance tests shall include, but are not limited to, the following: Wire Testing; The Contractor shall perform insulation resistance tests on each complete circuit prior to energizing. Insulation resistance between the conductors and between the conductors and ground shall not be less than 25 megaohms. 2. Operation Testing: The Contractor shall test the operation of each control panel and associated interlocks to verify proper functionality and performance. 3. RECORD DRAWINGS The Contractor shall be capable of providing electrical plans marked with any changes, deviations or addition to any part of the electrical work. The Contractor shall clearly indicate on as -built plans the following information: 1. All conduits runs installed 2. Locations of underground conduits and stubouts accurately dimensioned 3. Forming, cabling, and identification of all power and control circuits within pull boxes and terminal box City of Santa Ana RFP 21-122 On -Call Electrical Repair and Rehabilitation Services Page 15 CITY OF SANTA ANA RFP NO.: 21-122 ON -CALL ELECTRICAL REPAIR AND REHABILITATION SERVICES 4. All changes, deviations, in locations, routing, or dimensions or additions to any part of the electrical work 5. Interior views of each pull box identifying each conduit entrance by conduit number 4. TRAINING AND OPERATION MANUALS The Contractor shall offer training services and provide operation, maintenance and repair manuals consisting of all system drawings, block diagrams, schematics, shop drawings, and other pertinent data required to completely describe the operation and maintenance of the electrical system. The manuals shall be submitted prior to the final acceptance of the system and shall reflect the as -built conditions. The electrical system information in the operation and maintenance manuals shall contain: System operating instructions for normal operational conditions utilizing names of controls as they appear on nameplates 2. Calibration and maintenance instructions 3. Troubleshooting instructions 4. Instructions for ordering replacement parts 5. List of fuses, lamps, seals, and other expendable equipment and devices 6. Parts list including the make, model, and manufacturer of the equipment listed 5. EMERGENCY ON -CALL SERVICES The Contractor shall be able to provide emergency on -call electrical maintenance and repair services within four (4) hours of receiving the call. The Contractor's service technician is required to be on site and commence work within four (4) hours of initial contact if deemed by the City to be an emergency. The response time may be waived by the City if service can wait to be performed during Contractor's normal business hours. D. CODE COMPLIANCE All materials and workmanship shall be in strict conformity with standards of the latest editions including revisions of the following: • Institute of Electrical and Electronics Engineers (IEEE) • National Electrical Manufacturers Association (NEMA) • International Electrotechnical Commission (IEC) • National Electrical Code (NEC) standards • National Fire Protection Agency (NFPA) • American National Standards Institute (ANSI) • American Society of Testing and Materials (ASTM) • Insulated Cable Engineers Association (ICEA) • International Electrical Testing Association (NETA) City of Santa Ana RFP 21-122 On -Call Electrical Repair and Rehabilitation Services Page 16 CITY OF SANTA ANA RFP NO.: 21-122 ON -CALL ELECTRICAL REPAIR AND REHABILITATION SERVICES • National Electrical Contractors Association (NECA) • State Department of Industrial Safety (CAL/OSHA) • Underwriters' Laboratories (UL) • California Building Code (CNC) E. PROJECT MANAGEMENT AND COORDINATION When a request for service is issued by the City, the Contractor shall issue a project estimate and schedule to the City's designated Project Manager. The Contractor shall not proceed with any work without the approval in the form of a notice to proceed from the City's designated project manager. Contractors shall invoice the City on a monthly basis for all work performed during the period or provide a one-time invoice at the completion of work issued. Each invoice shall be accompanied by a summary of tasks performed, contract agreement number, results and progress on long-term tasks if any. F. VALUE ADDED RELATED SERVICES The Contractor may propose additional related services that the City has not specifically identified in this RFP to accomplish the stated goals of this RFP. Value added related services will be considered by the City and may or may not be incorporated in the agreement. All parts and materials must be supplied new and factory approved. G. SUBCONTRACTORS The use of Subcontractors is allowed, but will require approval by City prior to start of any assigned work. Upon commencement of work, the Contractor shall be responsible for services provided by any subcontractor as if Contractor were providing the services with its own organization. When a Subcontractor performs all or any part of the work, a markup shall be applied to the Subcontractor's actual cost of such work. The Contractor may add a markup of 10 percent on the first $5,000 of the subcontracted portion of the extra work and a markup of 5 percent on work added in excess of $5,000 of the subcontracted portion of the work may be added by the Contractor. H. MARKUP The following markup percentages shall be added to the Contractor's costs and shall constitute the markup for all overhead and profits (to the sum of the costs and markups, one (1) percent shall be added as compensation for bonding): 1) Labor ......................... .............. _........................................................ 20 2) Materials...........................................................................................15 3) Equipment Rental............................................................................. 15 4) Other Items and Expenditures.......................................................... 15 I. MINIMUM QUALIFICATIONS My of Santa Ana RFP 21-122 On -Call Electrical Repair and Rehabilitation Services Page 17 CITY OF SANTA ANA RFP NO.: 21-122 ON -CALL ELECTRICAL REPAIR AND REHABILITATION SERVICES The Contractor shall meet the following minimum qualifications: 1. All work is to be performed in compliance with all applicable codes, ordinances, laws, standards, due care, and Occupational Safety and Health Administration (OSHA) safety requirements. 2. The Contractor shall hold a current California C-10 Electrical Contractor's License. 3. The Contractor shall have a minimum of five (5) years of experience in providing industrial control panel building services. 4. The Contractor shall possess state and local permits, licenses and certificates required by law to commence, cant', and complete the work. 5. Provide all necessary equipment to competently perform and complete work as specified. J. SAFETY Proposer shall be solely and completely responsible for the condition of the project site, including safety of all persons and properties during the performance of the work. In addition, proper safety equipment must be worn at all times. These requirements shall apply continuously until the contract is terminated and shall not be limited to normal working hours. The Contractor/Consultant shall assure that each employee or subcontractor under the contractor's supervision is trained in the work practices necessary to safely perform his or her job. K. INSURANCE REQUIREMENTS The successful bidders shall furnish the City with original copies of valid insurance policies herein required upon execution of the contract and shall maintain said policies in full force and effect at all times during the term of this contract. Said insurance policies shall comply with all requirements set forth in these specifications. Contractor(s) shall keep a current certificate of insurance at the City of Santa Ana at all times and shall immediately report any changes to the City. L. FEE SCHEDULE Contractor shall submit a fee schedule as described in Section IV.B.3 of RFP. The Well 32 Reservoir Rehabilitation Plans provided as Exhibit A and the General Specifications in Exhibit B are to be used as the basis for completing the Fee Schedule form and any other documents requested below (assume all system integration programming will be provided by the City). Upon award of a contract, work will proceed as authorized by the City, but may not necessarily be the project as described in Fee Proposal (inclusive of Exhibit A and Exhibit B). No separately stated freight or deliveries will be considered. Bidders shall include all costs in the unit price bid. Furthermore, the Contractor shall submit additional labor, material and rental equipment rates along with fee schedule. Contractor's labor and equipment rate sheet shall list rates for all City of Santa Ana RFP 21-122 On -Call Electrical Repair and Rehabilitation Services Page 18 CITY OF SANTA ANA RFP NO.: 21-122 ON -CALL ELECTRICAL REPAIR AND REHABILITATION SERVICES labor designations, equipment, rentals, and materials. The bid items specified in the fee schedule are for reference purposes only. Labor increases shall be subject to mutually agreeable terms between the City and the Contractor. The City may request related services that will be paid at the vendor's standard labor and equipment rate submitted. Fee proposal shall be outlined as follows: ---End of SCOPE OF WORK Section --- City of Santa Ana RFP 21-122 On -Call Electrical Repair and Rehabilitation Services Page 19 EXHIBIT B 27 ■ �� `CCU ELECTRIC November 16, 2021 City of Santa Ana - Public Works Agency Attn: Armando Fernandez, P.E. 220 S. Daisy Ave. Bldg A Santa Ana, CA 92703 Ref: Statement of Qualification Dear Mr. Fernandez: RFP For On -Call Electrical Repair & Rehabilitation Services LEED Electric, Inc. Statement of Qualification LEED Electric, Inc. is pleased to submit this statement of quality commitment as the Electrical Contractor for the solicitation for the City of Santa Ana Electrical Repair & Rehabilitation Service contract. LEED Electric has provided quality services through a long 42 year history with the County of Los Angeles, the City of Los Angeles, County of Orange, Orange County Sanitation District, City of Santa Ana, Mesa Water District, the Metropolitan Water District of Southern California, the Department of Water and Power, Long Beach Water Department, City of Santa Monica Water Resources Division and most recently the Water Replenishment District (WRD) of Southern California and Los Angeles Wastewater Information Network System (LAWINS). LEED Electric, Inc. is a qualified Small Business Enterprise with the State of California Department of General Services as well as County of Los Angeles Office of Affirmative Action Compliance as an eligible participant in the County of Los Angeles Local Small Business Enterprise (LSBE) Preference Program. Numerous other public works projects have been successfully completed for virtually every local City and/or County governmental agency including Orange County Water District, Orange County Sanitation District, Los Angeles County Sanitation District, State of California Water Resources and other state agencies. LEED Electric, Inc. employs local tradesmen affiliated with the International Brotherhood of Electrical Workers and is signatory with IBEW locals from Ventura to San Diego County and complies with Project Labor Agreements (PLA). LEED Electric has extensive experience in industrial water related projects and intricate electrical control projects in the greater Los Angeles, Orange County and Riverside County areas. LEI is dedicated to on -time delivery of materials, labor and services for construction endeavors at all times, and along with the on -time delivery LEI responds to all inquiries for service in a timely and professional manner, with a commitment to provide the products or services meeting or exceeding the specifications of the customer. LEED Electric, Inc. (LEI) is a local full service electrical contractor with extensive experience in public works projects, having successfully completed hundreds of public works contracts during their 42 year history -from a high end of $7.OM to various projects in the $500K to $2.OM ranges. In summary; our team of local craftsmen overseen by an experienced management team that consists of a Chief Executive Officer, Operations Manager, Superintendents, Project Managers and Project Engineers to oversee quality products and services are provided and has the requisite expertise and experience in working as the electrical subcontractor for the City of Santa Ana. Some of our satisfied customers are included in the latter portion of this statement of qualification for reference. We hope you determine that our qualifications meet your requirements. Please contact me at sjamali@leedelectric.com leedelectric.com or (562) 270-9500 with any questions. Authorized Representative, yours truly, Seyed A. Jamali Dinan, Chief Executive Officer P a 1 e 1 1 13138 Arctic Circle, Santa Fe Springs, CA 90670-5508 LEED Electric Inc. ■ I �� Lm== I.1 ELECTRIC Company Information RFP For On -Call Electrical Repair & Rehabilitation Services LEED Electric, Inc. Statement of Qualification Firm Name LEED Electric, Inc. Corporate Office Address 13138 Arctic Circle, Santa Fe Springs, CA 90670 Corporate Phone and Fax Numbers Firm Phone # Firm Fax # (562)270-9500 (562)863-5723 Federal Tax ID # 95-3337191 Business Type S-Corporation Established 3/1/1979 in California DUNS No.: 09-916-2901 CAGE Code: OX1 H 1 Business License 0048-131380000-1 Exp. Date:06/30/2022 City of Santa Fe Springs, California License No. 379096 Exp. Date: 07/31/2023 Contractor License State of California Contractors State License Board A -General Engineering Contractor C-10 - Electrical Contractor DIR Contractor Registration DIR Registration No.1000004633 EXP. Date:06/30/2022 County of Los Angeles (LSBE) #139996 Exp. Date: 04/30/2022 SBE Certification State of California (Dept. of Gen Services) #36862 Exp. Date: 04/30/2022 NAICS 238210 Seyed A. Jamali Dinan, Chief Executive Officer Principals/Officers Annette Iribarren, Corporate Secretary & Controller Rodney Dean, Vice -President & Chief Estimator Years with Company Seyed A. Jamali Dinan: 8 years Rodney Dean: 18 years Telephone and Fax Numbers Phone # Fax # (562)270-9500 (562)863-5723 Name, Title, Phone No., and Email of Seyed (Seth) A. Jamali Dinan Contact Person for the Proposal (562)270-9500 sjamali@leedelectric.com Total # of Employees with the Firm 100 WebVen # 13999601 P a g s 12 13138 .Arctic Circle, Santa Fe Springs, C4 90670-5508 LEED Electric Inc. ®■ �� `MMLI ELECTRIC RFP For On -Call Electrical Repair & Rehabilitation Services LEED Electric, Inc. Statement of Qualification Company History, Structure and Capabilities AGREEMENT STATEMENT LEED Electric Inc. does not have any disputes with the Standard Agreement. BACKGROUND LEED Electric Inc. is an experienced and highly -recommended full -service commercial and industrial electrical, control & instrumentation contractor. The company has a reputation for completing projects on time, within budget and to the client's satisfaction. The company's comprehensive knowledge of new technologies combined with the highly trained staff and more than 42 years of experience performing heavy contracting work make LEED Electric a provider of choice. LEED Electric began operations in 1979 performing work at oil refineries, chemical plants and aerospace facilities. Later began doing public work for various municipal and county facilities on pumping plants, water treatment plants, and sewage treatment plants installing power and control systems, automation/measuring systems. MISSION The mission of LEED Electric is to provide highest quality electrical, control & instrumentation installations performed safely by highly trained, skilled craftsmen to meet or exceed customer specifications. VERSATILITY Contracts ranging to over $5.0 million have been successfully completed. Maintenance programs with special rates designed to fit customer needs have been provided. PERFORMANCE LEED Electric has a consistent record of completed projects on or before target dates. SAFETY Strict adherence to safety standards is an integral part of daily operations. COMMUNICATION LEED Electric's experienced management team is concerned about completing projects correctly and on time. The company understands that growing reputation depends on it. Constant communications with field personnel enables project managers to stay informed of job progress insuring smooth operation to timely completion. LITIGATION LEED Electric has not had any litigation or threatened litigation against the firm that will affect the company's performance or completion of this proposed program. a. The organization has never been subject of litigation for failure to meet contracted obligations to deliver or supply electricity since its inception in 1979. b. The company has no breach of contract or criminal legal actions with potential liabilities above $50,000 or involving imprisonment (now or pending) against the company itself, any official, officer or employee of the company submitting qualifications over the last 42 years. c. LEED Electric has not filed for bankruptcy, is not currently in default of business loans and is not responsible for undisputed payments to suppliers or transporters which are over 60 days past due. P a g e 13 13138 Arctic Circle, Santa Fe Springs, CA 90670-5508 LEED Electric Inc. ■ �� `CCY ELECTRIC Qualifications and Experiences RFP For On -Call Electrical Repair & Rehabilitation Services LEED Electric, Inc. Stateneent of Qualification In addition to the minimum qualifications for participation in this Maintenance Services Contract, LEED Electric offers: • 42 year history of excellent working relationship with public agencies throughout California • Southern California locally -based operations, with an Orange County office located in Aliso Viejo, and satellite offices in Fountain Valley, Santa Clarita and Playa Del Rey. • Experienced project managers and staff as relates to compliance with goal -oriented projects • Locally hired union workforce with vast manpower capabilities • LEED Electric is certified Small Business (SB-PW) by the State of California Department of General Services, (SBE) by the City of Los Angeles, and the County of Los Angeles Office of Affirmative Action Compliance as an eligible participant in the County of Los Angeles Local Small Business Enterprise (LSBE) Preference Program. • LEED Electric has prior experience in related projects and is extremely competent in the installation of Electrical, Instrumentation and Control Systems. • LEED Electric has previously held the Electrical Repair and Rehabilitation Services Contract since 2017 with the City of Santa Ana. P a g e 14 13138 Arctic Circle, Santa Fe Springs, Gt 90670-5508 LEED Electric Inc. 27 ■ �� `==LJ RFP For On -Call Electrical Repair & Rehabilitation Services ELECTRIC LEED Electric, Inc. Statement of Qualification Project Management Team Experience Led by Seyed A. Jamali Dinan, CEO of the company, the executive management team possesses impressive credentials, critical industry experience and education. The team, which comprises a combined industry experience of over 100 years, provides oversight and proficiency in all key functional areas of the business. (Seth) A. Jamali Dinan, Chief Executive Officer: As CEO of LEED Electric, Mr. Jamali Dinan enhances the company's leading posture in the industry by implementing new strategies and technologies in the field and for in-house operations. He is responsible for leading the company into new product development and new market expansion, assuring its continued growth and prosperity. Mr. Jamali-Dinan oversees all aspects of company operations including: estimating, project management, accounting, purchasing, contact administration, project development, customer relations, and employment development for all employees. � A _ Mr. Jamali Dinan has over 18+ of experience in the field of general and electrical contracting and provides the intuitive real and nuanced insights needed to detect and assess the most inconspicuous challenges and undefined subtle issues and exact the precise solution for any situation. Mr. Jamali Dinan actively serves as the guiding influence to the entire management team as well as the other members of the firm. Mr. Jamali Dinan obtained his Electrical Engineering degree from the University of Nottingham in the UK in 1999 later on attended the University of Southern California (USC) receiving his MS in Construction Management in 2006. Prior to joining LEED Electric, Mr. Jamali Dinan worked as a Project Manager for over 14 years for a major General Contractor in the US and successfully completed construction projects ranging from $32M to a high end of $225M in value. Rodney Dean, Vice President/Chief Estimator: As Chief Estimator, Mr. Dean is responsible for the oversight and organization deployment of an estimating department, utilizing an in-house proprietary computer estimating system developed over a twenty -six -year period. Mr. Dean joined LEED Electric in 2002 as Chief Estimator and over the ensuing 18+ years has focused mainly on projects in water and wastewater treatment industry. P a ; e 15 13138 Arctic Circle, Santa Fe Springs, CA 90670-5508 LEED Electric Inc. ■ �� L.CCLI ELECTRIC RFP For On -Call Electrical Repair & Rehabilitation Services LEED Electric, Inc. Statement of Qualification Darren Roesch, Operations Manager: The Operations Manager is to oversee all operations, coordinate safety plans, control the manpower, provide for equipment scheduling and insure the production standards and project schedules are met. Aid as a problem solver on the project and interact with the General Contractor, Project Managers and Foreman, insure the proper training and serve as a Mentor for the Foreman in his area of control in order to maintain the High Standards of the Company. Mr. Roesch's educational background includes: 1.B.E.W Local 11 Apprenticeship, Microsoft, Certified Systems Engineer, State of Calif. Journeyman Electrician License No. 132051, and Medium Voltage Cable Splicer. Mr. Roesch has 17+ years of experience, primarily on industrial projects consisting of petro/chemical, water/wastewater treatment, heavy manufacturing, inte net infrastructure, and TELCOM facilities. He specializes in process control automation and upgrading existing systems and plants. Effective labor management, completing projects on time and under budget, and being orientated toward customer satisfaction are additional strengths. Mr. Roesch joined the LEED Electric Team in 2016, but has worked on several past projects in this field, some of which include: • West Basin Municipal Water District, West Basin Phase V Expansion, where he worked as a Superintendent for the Phase V expansion from 20 MGD to 60 MGD and received an Electrical Excellence Award for the project, and the project contract was over $5 million dollars. • Castaic Lake Water Agency, Rio Vista Water Treatment Plant Expansion Project, he worked as a Superintendent in charge of a crew of Foreman and Journeyman Electricians for the construction of a treatment plant electrical and instrumentation expansion, and again was awarded an Electrical Excellence Award for the project, and the contract amount was over $7 million dollars. • Metropolitan Water District of Southern California, Joseph Jensen Water Treatment Plant, he worked as a Superintendent, in charge of the installation Fluorosilicic acid upgrades, new chlorination storage & treatment facilities in a project valued at over $8 million dollars. Mr. Roesch is a valued addition to the LEED Electric team, starting out as our Superintendent and receiving the promotion to Operations Manager, he continues to lead, learn, educate and mentor others with his extensive knowledge of water and wastewater treatment facilities and has helped insure the growth of LEED Electric. P a g e 16 13138 Arctic Circle, Santa Fe Springs, CA 90670-5508 LEED Electric Inc. 27 ■ �� `CCU ELECTRIC RFP For On -Call Electrical Repair & Rehabilitation Services LEED Electric, Inc. Statement of Qualification Gary Van Eede, General Superintendent: Mr. Van Eede has 28 years of experience. Primarily on industrial projects consisting of petro/chemical, water/wastewater treatment, heavy r manufacturing, internet infrastructure, and TELCOM facilities. He specializes in process control automation and upgrading existing systems and plants. Effective labor management, completing projects on time and under budget, and being orientated toward customer satisfaction are additional strengths. As Superintendent his role is to Manage day to day field activities on multiple projects; Detailing and problem solving on design build projects. Assisting daily in scheduling and planning of projects; Safety and QC ongoing daily; management of field installations and field staffing requirements. His Education and Experience: CSUDH Construction Management, Cerritos College — Structural Welding Technology, Industry Tenure: 30 years, Professional Affiliations: IBEW Local 11, Certifications: State Licensed Electrician No. 109612, City of Los Angeles Certified welder License 9 P027427, EPRI Level 2 Instrument technician, Attributes Relevant to Water and Wastewater Facilities: Large project Microfiltration and RO membrane experience, Extensive Design -Build experience and Multiple expansion projects successfully completed in operating facilities. Francisco Miranda, Superintendent: Mr. Miranda is a United States Marine Corp Veteran. His electrical education was obtained at Electrical Training Institute. He comes to LEED Electric with 17 years of experience. His experience is vast, but he has primarily worked on petro/chemical, water/wastewater treatment facilities, heavy manufacturing, internet, infrastructure and Telcom facilities. He specializes in process control automation, upgrading existing systems, electrical/instrumentation, and motor control. Mr. Miranda prides himself in effective communication, customer satisfaction, building relationships with the client and contractor/trades, he effectively manages daily project activities, meets deadlines and utilizes resources efficiently, so that projects come in under budget. As a Superintendent his role is to oversee the daily project activities on multiple projects, quality control, detailing and problem solving on design -build projects, field installation, and field staffing requirements. Mr. Miranda's professional affiliations include: IBEW Local 11 and National Electrical Contractors Association. Certifications: State Licensed Electrician No. 141714. P a g e 17 13138 Arctic Circle, Santa Fe Springs, CA 90670-5508 LEED Electric Inc. ZI■ �� `C C V RFP For On -Call Electrical Repair & Rehabilitation Services ELECTRIC LEED Electric, Inc. Statement of Qualification Cody Engelhardt, Superintendent: Mr. Engelhardt joined the LEED team in July 2020, as our Orange and Riverside County Superintendent, he is a state certified, journeyman electrician with over 10 years of experience in the electrical industry. The projects that Mr. Engelhardt has been involved with have ranged from small single -owner operations to Fortune 500 companies. Mr. Engelhardt is a goal -oriented individual with a customer service focus, he thrives in high energy, fast -paced work environments and enjoys working with others. His background includes all facets of electrical construction from ground up, to tenant improvement projects and service jobs as ajourneyman and a foreman electrician. Mr. Engelhardt is extremely organized and adept in keeping records from project tracking to crewmember staffing logistics. Some of the projects Mr. Engelhardt has completed and/or been involved with are Tustin Fire Station #37, Berth 200 PV System, Vista/ Valley Substation Control Building for Southern California Edison, Crafton Hills Pump Station, as well many more, such as Irvine Valley College - Technology Building, BBraun Pharmaceuticals - Mixing Tank Replacement 2017 & 2018. His qualifications are: California State License Number 9153070, OSHA 10 & 30, First Aid/CPR trained, Heat Illness, Arc Flash/Energized Work, QSP and Confined Space trained. Mr. Engelhardt is a great leader to our Orange County crews. Kevin Schwab, Senior Project Manager: Mr. Schwab started at LEED Electric in April 2019 and comes to us with over 40 years of experience in the Electrical Industry, some of his qualifications are noted in the latter of this statement following his career history, and He has been in past positions as Division Management and Business Development, Estimating, Purchasing Cost Management, and Logistics. Mr. Schwab supports the company as senior project manager bringing management level support to division personnel including estimators, project managers and superintendents, as well as interface with other trades for Electrical systems installations; Water/Wastewater, Oil and Gas, Underground Utility, Utility Grade Solar, Electrical Systems Infrastructure. Provide management level support to division personnel including staff management and training. Some of the projects Mr. Schwab has completed as Project Manager are: Los Alamitos High School Infrastructure Upgrade $ 10.5 Million, LA BCA DC Tillman Power Upgrade $ 7.7 Million Prime Contract MV Service and Infrastructure, OCSD P2 Demolition and UPS System Upgrade $4.8 Million, LACSD San Jose Creek $ 1.8 Million Sodium Hypochloride Upgrade, City of Torrance Arnie Basin $485,000 Flood Control Upgrade, LACSD Carson UV Demonstration Service Upgrade Prime $585,000 and EBX II Craton Hills Pump Station Upgrade $ 10.8 Million. As evidenced by his many years of successful employment in the industry and extensive training which includes IBEW Local 11 Member, Accubid, Primavera OSHA 30, TWIC Certified, Master/JW Electrician Certification and possessing his own C-10 Electrical Contractors License, he brings skilled professional abilities in multiple fields of performance to each project. As a manager, he has the interpersonal skills needed to lead and direct others, while maintaining the integrity and timing of the overall project. P a � e 18 13138 Arctic Circle, Santa Fe Springs, CA 90670-5508 LEED Electric Inc. 27 ■ �� `C C Y RFP For On -Call Electrical Repair & Rehabilitation Services ELECTRIC LEED Electric, Inc. Statement of Qualification Michael Sanchez, Senior Project Manager: Mr. Sanchez started at LEED Electric in August 2020 and comes to us with 24 years of experience in the Electrical Industry and joins this team as a Senior Project Manager. He spent most of his career as a Senior Project Manager working for Rosendin Electric where he managed projects from $2M to $10M. Mr. Sanchez, has also served as reputable operations manager, senior project manager, field superintendent, and foreman with more than 24 years of experience directing new development, expansion, and renovation initiatives for a number of top-ranking electrical contractors. Consistently meeting key project deliverables while ensuring superior quality and client satisfaction. Talented communicator, with demonstrated success in building valuable relationships with personnel, vendors, clients, city officials and government entities. Expertly manages multi -million -dollar projects for a wide range of sectors including transportation, municipal, hospitality, office, residential, gaming, retail, education, and healthcare. Areas of expertise include: Electrical Contracting Operations, Project Lifecycle Management, Contractor Management, Quality Assurance Team, Leadership, Recruitment, Training & Development, Budgeting & Estimating, Planning, Procurement Blueprints & Specifications, Safety Awareness, Scheduling, Client & Vendor Management. Some of his career background consists of: • Operations manager for the Ontario office location managing Project Management and Field Operations Managed numerous Projects between 250k- 7M as a SR. PM. Managing 3 PM's, 3 PE's, 2 PA's, Warehouse, Prefab, 18 Foreman, 50-100 field employees. Bid reviews, Cost to complete for 20+ projects. Directly report to Executive Vice President. • Senior Project Manager on Kaiser Hospital Projects $42M+ DB/DA and High rise in Downtown LA 12th & Fig. Signage. Manage all aspects pertaining to electrical portion of project, report to the Division Manager • Managed 3 large projects simultaneously all valued at $10M+ • $142M initiative to expand the 2M+ sq. ft. 2.4B$ McCarran International Airport Facilitated project startup within 90 days of notice to proceed; included purchase orders & submittals for all material deliverables. P a g e 19 13138 Arctic Circle, Samna Fe Springs, CA 90670-5508 LEED Electric Gec. 27 ■ �� `C C Y RFP For On -Call Electrical Repair & Rehabilitation Services ELECTRIC LEED Electric, Inc. Statement of Qualification Paul Bergeron, Senior Project Manager: Mr. Bergeron joined Leed Electric in December 2020 with an extensive background of 13 years of experience in the electrical industry by completing his Journeyman Wireman Program at Sanitago Canyon College in 2007 and receiving is certified general wireman license. Some of his education accolades are Electrical Project Supervision (EPS) 1-3, OSHA 30-Hour Certification, First Aid and CPR Certification, Anti -Harassment Training, Pricing and Negotiating Change Orders and Claims Like a Pro Seminar, and Procore — Project Manager: Core Tools Certification. Some of the aspects he handles at Leed are Manage Project Engineer and Other Support Staff for Multiple Projects, Develop, Review and Coordinate Schedules with Owners, General Contractors, Subcontractors, and Field Superintendents. Review Bid Documents for Schedule Impacts, Conflicts with Other Trades and Potential Manpower Issues, Request, Review and Process Potential Change Orders, RFI's, ASI Drawings and Submittals, Provide Detailed Labor and Material Take- Offs/ROM's/Estimates/Change Orders for Scope Changes and Bids, Order Buy -Out Quotation Materials and Systems, Monitor Drawing Approvals and Schedule Material Arrivals, Coordinate the Procurement, Delivery, Installation, QA/QC, Testing, Startup, Commissioning and Close -Out of Multiple Projects, Provide Acceptable Billing Breakdown and Monthly Billings to the General Contractor and Coordinate with Various Jurisdictional Authorities and Update Owner on Inspections, Shutdown Requests, Job Walks, Schedule and All Other Activities. Some of the project he has worked on are: • OCWD — YLWD — HQ PFAS $2,489,063 • SoCal Gas — Industrial Electrical Services $4,000,000 • SDGE— Industrial Electrical Services $1,000,000 • LACDPW — West Coast Basin Barrier Project Unit 13 $1,021,941 • LACDPW — Low Flow Diversion System Wide Update $1,150,000 • IRWD — ZARRPS — Zone A Rattlesnake Reservoir Pump Station $2,287,000 • TIWRP — CIP 8170 — CISCO 1 I — HWRP IPS Screw Pump No. 9 Replacement $35,654 • TIWRP — CIP 8542 — CISCO 10 — Advanced Water Purification Facility Phase 1 Chemical Piping Replacement $389,897 • TIWRP — CIP 5249— CISCO 10—EPPPump #3Train Rehabilitation $160,887 • City of Oceanside — Oceanside Beach Operations Facility and Restrooms Project Mr. Bergeron has improved his skills in this industrial and knowledge and connections while working for other major competitors in this industry such as starting out as a Project Engineer at Morrow -Meadows Corp, then Assistant Project Manager and finally to Project Manager over a 10-year career while at Morrow -Meadows, as well as working for Anderson and Howard and Giannelli Electric and Whiting -Turner Construction for a few years before coming to Leed. We look forward to all that Mr. Bergeron has to offer and utilizing his extensive network base, skills and knowledge of this industry in the many years to come. P a g e 110 13138 Arctic Circle, Santa Fe Springs, CA 90670-5508 LEED Electric Inc. ■ �� IOCCY ELECTRIC RFP For On -Call Electrical Repair & Rehabilitation Services LEED Electric, Inc. Statement of Qualification Antonio Bracamontes, Project Manager: Mr. Bracamontes joined LEED Electric, starting in August 2015, but he has over 18+ years' experience in the Industrial Electrical Project Management Field specializing in water and wastewater treatment facilities construction management. Mr. Bracamontes currently working as a Project Manager for LEI on several of its current projects and has also managed several industrial water/wastewater projects in the past some of which include: • City of Cypress Department of Public Works, Myra Ave. Pump Station No. 2 Reconstruction, worked as a Project Manager, interfacing with the Owner and General Contractor to coordinate the installation of a new Motor Control Center, VFDs, Pumps, a SCADA System and backup generator at a 45 year old pump station rehabilitation to prepare for the 100 year flood. • Irvine Ranch Water District, Orchard Hills (PA1) ILP Turnout, worked a Project Manager to coordinate and oversee the installation of flow meters, pressure transmitters, an antenna mast, site lighting and electrical conduit and wiring for the new station for the water district. • Irvine Ranch Water District, Zone 3 to 4 Domestic Water PRV Site Northwood Reservoir, again worked as a Project Manager to oversee the Feld construction of the PRV station for the water district. Coordinated the installation of new MOV's, a service pedestal, pumps, and instrumentation. Mr. Bracamontes has Bachelors of Science in Electrical Engineering, emphasizing in Communication from the California State Polytechnic University, Pomona. Prior to joining LEED Electric, Mr. Bracamontes worked as a Project Manager for over 13 years for another local contractor, Beard Electric in Santa Fe Springs and 2 years working as an Electrical Systems Engineer with Trams International, Inc. before joining the Leed Electric team. P a g e 111 13138 Arctic Circle, Santa Fe Springs, CA 90670-5508 LEED Electric Inc. ■ �� `CCY ELECTRIC RFP For On -Call Electrical Repair & Rehabilitation Services LEED Electric, Inc. Statement of Qualification Jerry Romero, Project Manager: Mr. Romero joined LEED Electric in June 2018 to be a part of its Project Management Team. Mr. Romero has over a combined 23 years of experience in the electrical and instrumentation & controls industry. This includes site field superintendent positions in the heavy industrial construction sector, with a specialty in the water/wastewater, chemical plants, booster and lift stations. Mr. Romero has managed many industrial water/wastewater projects, some of which include: • City of Perris chemical treatment plant: This project consisted of a new freshwater treatment facility. Included in the scope of work were underground duct banks, manholes, service board, MCC, Pumps, instrumentation & controls, SCADA, PA and fire alarm systems. • City of Long Beach Haynes facility: This project was a design build reverse osmosis plant. Included in the scope of work were new pumps, VFD's, MCC's, motor operated valves and instrumentation and controls. • City of Anaheim, Lenain Water Treatment Plant, Contract Value: $23M, Installation of Switchgear, Motor Control Center, VFD's, Instrumentation and Control Panels, and Lighting. Role: Project Manager • Mission Village Temporary Pumping Plant and Force Main for new construction in the Valencia area. Installation of conduit, wire, Switchgear, Motor Control Center, new VFD's, Instruments, Control Panels and Lighting for a ground up new construction pump facility. Contract value: $664,488, role was Project Manager. Mr. Romero experience of accountability included submittals, material procurement, scheduling of field crews, as well as sub -contractors and startups. Michael Gomez, Project Manager: Mr. Gomez brings more than 15 years of experience to his current role. He has performed many functions in the industry, attaining a foundation in the field as an electrician, and leading in roles such as Project Engineer, Assistant Project Manager and Project Manager. Mr. Gomez actively participates in project bids, project development, managing schedules and discerningly managing project deliverables. His responsibilities entail initiating projects, project planning, executing, monitoring and controlling, and the successful projects close- out. He has a bachelor's degree in Electrical Engineering and hold a General Electrician license. He is proficient in Bluebeam, Accubid and Microsoft office. Mr. Gomez completed projects are as follows: Los Angeles Federal Courthouse, MCAGRCC — Generator Upgrade, Orange County Sanitation District P24 10, LACSD JWPCP Power Service for the Advance Water Treatment Demonstration Facility. He is currently the Project Manager for the OSCD P2 A — Side Primary Clarifiers Replacement project. P a g e 112 13138 Arctic Circle, Santa Fe Springs, CA 90670-5508 LEED Electric hie. ■ �� `CCY ELECTRIC RFP For On -Call Electrical Repair & Rehabilitation Services LEED Electric, Inc. Statement of Qualification Karen Ankenbauer, Assistant Project Manager: Ms. Ankenbauer has been in the electrical construction industry since 1999, starting at a small shop in the Los Angeles area (Angeles Electric) that mainly did TI and commercial work in the LA and Long Beach areas. Some of the project highlights at Angeles Electric were the: Marion Davie Rehab and Reuse project in Santa Monica, Solar project at Burbank Airport and four floors at the Doctor's Hospital project. Some of Ms. Ankenbauer' responsibilities at Angeles included (not limited to): Billing, Collections, Completing Prequalification's, Preliminary Notices (and tracking 30, 60, 90 days after final labor so we didn't lose our lien rights), T&M pricing and billing, Change Order processing and updating SOV's for billing. From Angeles Electric Ms. Ankenbauer went to Doty Bros. where her primary functions were Bid Coordination, Job Walks, Some Estimating, submittals, and following through on contract documents, some projects were the Morris Dam, Oxnard Advanced Water Purification Plant, and Weymouth MWD. From Doty Bros. Ms. Ankenbauer went to Neal Electric where she focused on change orders, billing, collections, assisting the division manager, Prequals, PLA documents, writing subcontracts and major PO's following through with the PLA documents for compliance, bid advertisements, and office facilities. Some of the highlight projects at Neil were the Haynes Power Plant, Long Beach Pumping Plant, & San Jose Creek. After Neal Electric Ms. Ankenbauer went to A-C Electric as a Project Assistant where she did everything from contract routing, PLA documents, submittals, change orders, RFI's, job walks, pre -job orientation meetings, bid/contract scope reviews with the PM's, major PO buyout reviews, billing, collections, assisting PM's with their projections. Some of the project highlights were the Jockey Pump at Port Hueneme, Roosevelt High School (LAUSD), Santa Ana Jr. College Student Center. Programs: Textura & Procore License: Notary, Completed: Basic Estimating at LA NECA. Sepehr Fanaeian, Project Engineer: IrMr. Sepehr Fanaeian has been with LEED Electric since August 20t7. He has 9 years of experience in Electrical and Control Engineering field. He worked for 5 years with Science Instrument Co. in Baltimore, Maryland as well as overseas in Haifa, Israel at the Baha'i World Centre in the Engineering Department - Electrical/Control Engineering Management Team for more than 4 years of his stay there. He has extensive experience on electrical system project and upgrading of control and security � _Z systems. Mr. Sepehr Fanaeian has a Bachelor of Science in Electrical Engineering Degree, with Electronics Minor from BIHE — online University in Tehran, Iran, and he continued his post -baccalaureate at the University of Maryland — UMBC. Mr. Fanaeian is responsible for the production of project submittals, from generation to approval and tracking these documents, field RFI's, and supporting the Project Manager, Superintendent and Field Foreman, attending meetings, generating schedules and tracking materials and gear to ensure on -time delivery. P a g e 1 13 13138 Arctic Circle, Santa Fe Springs, CA 90670-5508 LEED Electric Inc. r m �� `CCLI ELECTRIC RFP For On -Call Electrical Repair & Rehabilitation Services LEED Electric, Inc. Statement of Qualification Abdel Hamid, Project Engineer: Mr. Hamid joins the Leed Electric team most recently in October 2020 possessing a strong education Bachelor of Science in Electrical Power Engineering Technology, University of Houston, College of Technology, with experience and skills that consist of: Proficient in MS Office, Bluebeam Revu, AutoCAD, Electrical Circuit & Power Systems Analysis, Basics of C++ Programming, Matlab, MIPS, VHDL, PLCs, Altium Designer, AutoCAD, SAP and Accubid. He plans to apply his technical knowledge, analytical skills, and achieve hands-on experience in a leading organization while expanding his electrical design knowledge and workplace competency through continuous research and training. Additionally, his previous job facilitated in him being committed to quality, continuous improvement, and the ability to function effectively as a member of a team with the highest professional and ethical standards. He comes to us with skills as a Project Engineer managing multiple low voltage subcontractors, submittal processing, RFI's, coordination of trades, Oversee QA/QC procedures for low voltage systems and experience assisting with change orders and negotiations for added scope. Cindy Roman, Project Coordinator: Mrs. Roman joins the Leed Electric team most recently in August 2021. She comes to us with skills as a strong Project Administrator assisting in multiple projects ranging from 18 million- 32 million dollars. Mrs. Roman has also Provided T&M processing and Auditing at Jet Propulsion Lab for a contract value of $13 million which includes Change Order processing and updating SOV's for billing. Some or her other abilities include managing all project document control inclusive of billings, submittals, project access, procurement, Field Time Cards, GC Dailies and Safety documentation. Programs Procure and MS Office. Completed Basic Project Management NECA courses. P a g e 1 14 13138 Arctic Circle, Sonta Fe Springs, CA 90670-5508 LEED Electric Inc. 27 ■ �� LOCCLI ELECTRIC RFP For On -Call Electrical Repair & Rehabilitation Services LEED Electric, Inc. Statement of Qualification Anthony Santoro, Preconstruction Engineer: Mr. Santoro started with Leed Electric in August 2015, although his career in the electrical industry began with Beard Electric in Santa Fe Springs, California in 2004. He has over 10 years' experience working as an assistant PM/Support Staff at Beard Electric and looks to take on more challenging rolls now at Leed Electric in the coming years of his career. He worked as an assistant PM on several water and wastewater projects working with fellow employee Mr. Bracamontes while at Beard Electric, generating submittals, RFFs and assisting with purchasing and change order management. Currently with Leed Electric Mr. Santoro works as a Preconstruction Engineer, overseeing Estimate preparation and procurement of project plans and specifications as well as interfacing with General Contractors and attending pre -bid meetings and generating company prequalification packages and successfully obtaining prequalification's for LA County Department of Public Works, City of Santa Ana, Water Replenishment District of Southern California and Mesa Water District, most recently Chino Basin Desalter Authority and the City of Seal Beach as their Electrical Maintenance Contractor. Mr. Santoro previously worked on submittal packages for both in house submittals and packing vendor submittals along with processing RFFs all of the Time and Material Estimates / Change Orders and supported the Project Managers, Field Operations Manager and Executive Supervisors with delegated tasks, before being promoted to the Estimating Department where his current focus is estimating support, bid packages, and prequalification, to pre -con responsibilities. Mr. Santoro also helps in processing work orders for the current On -Call Operations Telemetry System Maintenance Services Project with LACDPW in the capacity of supporting the field crewmembers as well as office management staff, to ensure purchases are made on time and work orders are scheduled and completed in a timely and professional manner. Mr. Santoro graduated with an Associate's Degree in Administration of Justice from Long Beach City College and looks to further his knowledge of project management, preconstruction and supervisory skills while working with the Leed Electric team. P a g e 1 15 13138 Arctic Circle, Santa Fe Springs, CA 90670-5508 LEED Electric Inc. ■ �� I. C C Y RFP For On -Call Electrical Repair & Rehabilitation Services ELECTRIC LEED Electric, Inc. Statement of Qualification Daniel Flores, IBEW Certified Electrician: General Foreman Electrician: Mr. Flores has been with Leed Electric, Inc. since 2004, and has completed the IBEW apprenticeship program and worked for Leed Electric as an Apprentice and graduated to Journeyman and was promoted to Foreman then General Foreman. Mr. Flores is OSHA 10 and 30 certified and completed Confined Space Training, and graduated with an Associate Degree in Liberal Arts from Santa Monica College. He has worked on and completed several projects for Leed Electric which some are listed here: • LACDPW Compton Creek, Foreman demo of existing conduits, wires and controls at lift station facility to run new conduit and wire for new engines and pumps installed at the facility by the general contractor. Installed gas detector system and propane gas backup for engine operations, conducted field testing and started up system. Installed field site lighting and inside pump station, conducted field meetings and coordinated work with project manager and general contractor, the project concluded in 2015. Position: Foreman • LACDPW Terminal Island WRP Tertiary Filters Rehabilitation, Foreman Installed conduit systems and wiring to new MOV's at the sand filter area, installed new control panel for new MOV's and pulled analog, control and power wire to (64) new MOV's, the project was completed in 2015. Position: Foreman • West Basin Municipal Water District Edward C. Little Water Recycling Facility Clean -in -Place Waste Discharge Project, Foreman Worked on field layout and material procurement and installation. Made field installation schedule for project, conducted safety meetings, started the project from underground conduit installation and up, installed utility conduit run, installed new Switchgear, MCC and lighting. Ran conduit and wire in the pump station and treatment system, tested system and startup conducted. Managed installation and coordination with owner and general contractor to complete the project in late 2018. Position: Foreman • City of Los Angeles, Venice Dual Force Main and Generator Installation, General Foreman, he has overseen the installation from underground PVC conduits to above ground GRC and PVC Coated conduits. He has assisted in the redesign and installation of (2) large Cummins generators. Installation of new control panels, Switchgear, Instrumentation and Controls, The project completed in late summer 2019. With the training and experience working for Leed Electric for so many years Mr. Flores is qualified for any wastewater project that LEI is awarded and in currently supervising several LEI projects in his General Foreman capacity where he will oversee a Foreman and his crew to ensure the project is completed on time and per spec. P a g e 1 16 13138 Arctic Circle, Santa Fe Springs, CA 90670-5508 LEED Electric Inc. 27 ■ �� `C C Y RFP For On -Call Electrical Repair & Rehabilitation Services ELECTRIC LEED Electric, Inc. Statement of Qualification Edgar Saldivar, IBEW Certified Electrician: General Foreman Electrician: Mr. Saldivar has over 18 years of Commercial and Industrial experience. Adept in performing electrical installations, maintenance, and repairs in water plant facilities; knowledgeable in all areas of the national electrical code; and excel in analyzing and solving problems with various electrical controls and systems. For the past 5 years, as a Foreman, Mr. Saldivar has completed several projects in Los Angeles County. The following projects executed by Mr. Saldivar are as follow: • San Jose Creek Water Reclamation Plant, in Whittier, installed a Unit Substation 1C2-1D2 and associated electrical duct banks, cable trays, manholes, pull boxes and 5-kv conductors. At the Sludge pump station, I coordinated the installation of VFCs, switchboards, panelboards, transformers, Control Panel and instruments. • Terminal Island Water Reclamation Plant: Microfiltration, reverse osmosis and chlorination underground duct banks, manholes and Prefab Electrical Rooms. Control Panels and all Instrumentation such as FITS, PITS, DPITs, LITs AITS, • Maywood Mutual Water Company, in Huntington Park, the electrical room with ATS and Generator was modernized. Installed new Backwash Pump, Reclaim Pump, Sludge Pump Microfiltration vessel with MOVs, DPITs, FITS and PITS. • Mesa Water District, Well Automation and Rehabilitation Project at Mesa Wells 1, 3, 5, 7 and 9 spread across the city of Costa Mesa. The work included, the upgrades of the wells, pump replacement, gas engine replacement, general electrical equipment replacement, new emergency generators, construction of new chemical storage and feed systems area, replacement of wellhead piping, instrumentation upgrades, and site security improvements, with the contract constraints that only I well could be offline at a time and there was a schedule as to when it was okay to take wells offline. Work for this project took place in 2 shifts with Mr. Saldivar working as the General Foreman, overseeing both day and night activities due to project requirements. Mr. Saldivar is a Certified General Electrician and has obtained a C-10 state license and has completed the following courses; code, instrumentation, and foreman courses at Electrical Training Institute through IBEW. Edgar has the skills to complete any instrumentation project and is currently working for the City of Santa Ana as the maintenance contractor of choice for several of the cities Pump Stations and Treatment Systems. As well as working for Mesa Water District in a service contract for their reservoirs and has expertise in this industry that is very hard to match. P a g e 117 13138 Arctic Circle, Santa Fe Springs, CA 90670-5508 LEED Electric Inc. 27 ■ �� `MMU ELECTRIC RFP For On -Call Electrical Repair & Rehabilitation Services LEED Electric, Inc. Statement of Qualification Joseph Evanilla, IBEW Certified Electrician: General Foreman Electrician: Mr. Evanilla came to Leed Electric in early 2020 as a General Foreman Electrician, with more than 35 years of experience planning, developing, and implementing construction projects. Extensive understanding in Public Works Water Production. Mr. Evanilla has spent his careering working for A & B Electric Company, then over to Morrow -Meadows Corp before joining Leed Electric. His career and training highlights are EPRI Certification, AC/DC power and control systems, Electro-mechanical proficiency, Complex issues management, Understanding of client business requirements, Strong customer focus, Works well in team environment, Blueprint takeoff, Project layout, Control schematic production and an Extensive knowledge in electrical tools and equipment. Some of the many projects Mr. Evanilla has completed are listed here: LAXFUEL Corporation, 4 TANK Project 2019, Metropolitan Water District, Joseph Jensen WTP Plant Electrical Upgrades Stage IA 2018, City of Chino, Eastside Water Treatment Plant 2016, Three Valleys Municipal Water District, San Antonio Spreading Grounds 2014, City of Brea, La Florista Sewer Lift Station 2014, City of Covina, Charter Oak Reservoir 2014, Fontana Water Co., Sandhill Hydroelectric Generators Plasent 2013 and Rancho Cucamonga Water District, Arthur Bridge WTP 2013 and many more dating back to 2003. Mr. Evanilla is a valued addition to the Leed Electric team with his unmatched experience, skills and leadership qualities. Michael Marshall, IBEW Certified Electrician: Foreman Electrician: Mr. Marshall joined Leed Electric in 2016; he completed the IBEW Five Year Apprenticeship Program in 2016. Mr. Marshall has previous experience working for Neal Electric working on water and waste water projects. When Mr. Marshall joined Leed Electric in 2016 he began working on several water and wastewater treatment projects in varies stages of completion. Some of the projects Mr. Marshall has completed are the following: • Los Angeles Wastewater Integrated Network Systems (LAWINS), working with the integration at Hyperion Treatment Plant under the supervision of our General Foreman Instrument Tech. • 2017 West Coast Basin Barrier Telemetry Project, for Los Angeles County Department of Public Works, upgraded the existing telemetry system by adding new PLC's with battery backup, re -terminated the system to work with the new interface. For the West Coast Barrier reach of the Seawater Barrier System for LACDPW. Position: Journeyman • Currently working on the Seawater Barrier Maintenance Contract as the dedicated Certified Electrician, when WO's come in he reviews the requirements and completes the necessary work for the Los Angeles County Department of Public Works. Installing new sensors, troubleshooting, working with our subs troubleshooting communication issues and solving these problems so that County may have a working monitoring system. Mr. Marshall has also worked on projects such as the West Basin Project Phase V, LAX/Crewshaw Transit Corridor and has some experience in Photovoltaic Systems in his training. While at Leed Electric he has worked under the direction of Miguel Chavez working on the Telemetry Projects recently completed by Leed Electric and has valuable expertise at the Barrier Systems. P a g e 118 13138 Arctic Circle, Santa Fe Springs, CA 90670-5508 LEED Electric Inc. ■ �� `CCY ELECTRIC RFP For On -Call Electrical Repair & Rehabilitation Services LEED Electric, Inc. Statement of Qualification Sergio Hernandez, IBEW Certified Electrician: General Foreman Electrician: Mr. Hernandez completed the IBEW Apprenticeship Program; He has over 11 years of electrical experience in this field. He joined Leed Electric in 2016 working on several water and wastewater treatment projects in varies stages of completion. Some of the projects Mr. Hernandez has completed are the following: • 2010-2012 Morris Dam provide and install switchgear, MCC, PLC, Control Panels, 6 MOV's, FIT's, PITS, Generator, and Lighting for the Dam. Position: Journeyman • 2013-2016 San Jose Creek Ras Pump Station - Install substation, Manholes, MCC, PLC, Control Panels, VFC's, FIT's, LIT's, PIT's, and installed medium voltage cable. Position: Journeyman • 2016 Long Beach Pump Station- installed Bus Duct, switchgear, MCC, PLC's, Control Panel's, VFC's, 6 MOV's, vibration switches, and fire alarm. Position: Foreman • 2017-Current Santa Anita Dam Spillway Modification Project, Position: Foreman, overseeing the installation of underground and above ground conduits, above, below and on the Santa Anita Dam face. Safety is his top priority while supervising this projects crew. The work consists of installing Lightings, as well as helipad lights, Manual Transfer Switch, UPS, Generator Connections, Cable Tray Systems and Fiber Optic Cable and Hardware. Mr. Hernandez has a solid work ethic and keeps close eye on safety performance of not only his crew, but of crews working alongside so as to ensure nothing dangerous goes on with a potential for injury. Mr. Hernandez is an asset to LEI. Christian Tomren, IBEW Certified Electrician: Foreman Electrician: Mr. Tomren joined Leed Electric in 2017; he completed the IBEW Electrician Program in 2009. Hejoined Leed Electric in 2017 working on several water and wastewater treatment projects in varies stages of completion. Mr. Tomren has many qualifications, which are: CA General Electrician Certified 2008, Advanced Lighting Control 2013, Solar PV/Installer 2009, OSHA 10 & 30, First Aid, CPR Trained, Confined Space Certification and can operate several different types of construction equipment with different certifications. Some of the projects Mr. Tomren has completed are the following: • Mr. Tomren completed the MWD Advanced Water Treatment Demonstration Facility, General Foreman Electrician. • CIP 5233 Terminal Island Advanced Water Purification Facility Doubled Capacity of Clean water to 12 MGD. Installed two new 200HP VFD. New MF Facility and Electric Room with 2 60 HP VFD's. New RO Facility and Electric Room with 2 500HP VFD's. New AOP UV System Facility. 10 Chemical Metering Pumps and new Sodium Hypochlorite Facility. 3 125 HP Product Water VFD's. New UPS System for 8 PLM's. 3 New Man Holes and Associated Duct Banks. 8 PCM Demo and Installation of New PCM's. Managed 2t Electrician's during the peak of the project. New MCC inside main electric building. Position: General Foreman Electrician • Carbon Canyon Water Recycling Facility, PLC Upgrades, Install New Conduit and Wire, 4 New PLC's and Cutover 1 train at a time. New Server Room. Position: Foreman Electrician Mr. Tomren has the proven ability to schedule/manage employees while maintaining maximum productivity, and is an excellent addition to Leed Electric and is prepared for any project, and is a valued asset to have a part of our team, ready to tackle what may come ahead. P a g e 119 13138 Arctic Circle, Santa Fe Springs, CA 90670-5508 LEED Electric Inc ■ �� LEMOU ELECTRIC RFP For On -Call Electrical Repair & Rehabilitation Services LEED Electric, Inc. Statement of Qualification Sean Eagle, IBEW Certified Electrician: Foreman Electrician: Mr. Eagle joined Leed Electric a few years back and has been a Union Electrician since 2011 with Orange County IBEW Local 441. His education began at Brooks College where he received his Associate's Degree in Programming and Networking. Shortly after he began his electrical education with the union where he became a State Licensed Electrician. Mr. Eagle also has several certifications, those in CPR and first aid, High -reach fork lift, and Hilti powder actuated gun. His job responsibilities in the past have included, Chapman University, Mary Pickford Theater, Fox Studios, solar in Huntington Beach Civic Center, utility yard and library, solar at George F Bailey Detention in Chula Vista, solar at Kaiser in Yorba Linda and solar in schools, new construction High Rise buildings in Fashion Island and Irvine, commercial Tenant Improvements, and multiple parking structures. Mr. Eagle joined Leed Electric in 2017 as a 5th year apprentice and became a Foreman officially in September 2018. He has lead projects at Mid -Basin, Orange County Water District, and Temescal Valley Water District Water Reclamation Plant Phase IV Expansion as well as assisted at Mesa Well Automation, Mesa Water District. Mr. Eagle is currently leading the Yorba Linda Water District HQ PFAS Water Treatment Plant located in Yorba Linda for the Orange County Water District. a �; 20 13138 Arctic Circle, Santa Fe Springs, CA 90670-5508 LEED Electric Inc. r 0 �� L■CCY ELECTRIC Additional Project Experience RFP For On -Call Electrical Repair & Rehabilitation Services LEED Electric, Inc. Statement of Qualification Project No. 1 Project Name Seawater Barriers Maintenance Services for Telemetry System and Appurtenances 2015-2020 Location Los Angeles County, CA Owner County of Los Angeles Department of Public Works Project Manager Name Adam Lee, P.E. E-mail and Telephone No. (626)458-6185 awlee@dpw.lacounty.gov Contract Value $416,309.00 Annually (including change orders) Electrical and Instrumentation Maintenance for LA Counties Seawater Brief Description of Firm's Scope of Barrier Injection Wells and Observation Wells. Installation of sensors, Work for the Project instruments, conduit, wire, testing of instruments and equipment as well as water levels with sounder tool. Over 30 wells in the Long Beach, Wilmington, Carson area. Completion Date July 2020 Project No. 2 Project Name On -Call Consultant Services for the Los Angeles Wastewater Information Network System (LAWINS) Location Playa Del Rey, CA Owner City of Los Angeles, Department of Public Works, Sanitation Bureau Project Manager Name Tim Makela E-mail and Telephone No. 310-648-5920 timothy.makela@lacity.org Contract Value $ 7,300,000.00 (including change orders) Brief Description of Firm's Scope of Instrumentation and System Integration for Honeywell DCS Cutover, Testing Work for the Project of over 15,000 field instruments and replacement of over 100,000 LF of Instrument and Power Cable (HWRP, TIWRP, DCTWRP & LAGWRP) Completion Date December 2019 P , - 1 21 13138 Arctic Circle, Santo Fe Springs, CA 90670-5508 LEED Electric Inc. 27 ■ �� `CCLI ELECTRIC RFP For On -Call Electrical Repair & Rehabilitation Services LEED Electric, Inc. Statement of Qualification Project No. 3 Project Name Burris Pump Station Phase 2 Location Anaheim, CA Owner Orange County Water District Project Manager Name Ryan Bouley E-mail and Telephone No. (714) 378-3200 rbouley@ocwd.com Contract Value $ 2,501,583.50 (including change orders) Electrical and Instrumentation for a new pump station. 4160V, 2000A New Brief Description of Firm's Scope of Service, CITY (4) 1750HP 4160 VFD's 2000A Motor Control Center Work for the Project Installation, Allen-Bradley PLC, HMI and SCADA Installation and installation of a 12KV/4.2KV Transformer. Completion Date November 2017 Project No. 4 Project Name Regional Treatment Plant Cogeneration & Switchgear Upgrade Project Location Laguna Niguel, CA Owner South Orange County Wastewater Authority Project Manager Name Mike Matson & Brian Peck E-mail and Telephone No. (949) 234-5400 mmatson@socwa.com & bpeck@socwa.com Contract Value $ 1,811,025.28 (including change orders) Brief Description of Firm's Scope of Demolition of existing conduit and wire, furnish and install underground Work for the Project conduit, manholes, 2,000FT of 12x750MCM XHHW Power Feeder Wire, Instrument Cable, Switchgear, Cogeneration Engine, PCL and SCADA Completion Date July 2018 Project No. 5 Project Name Dominguez Gap Barrier Telemetry Systems Location Los Angeles County Owner County of Los Angeles Department of Public Works Project Manager Name Adam Lee, P.E. E-mail and Telephone No. (626)458-6185 awlee@dpw.lacounty.gov Contract Value $ 2.1M (including change orders) Brief Description of Firm's Scope of Furnish & Install 9 Miles of Fiber Optics, Power and Instrumentation Cable Work for the Project for SCADA and Telemetry System and Flow Diversion. Completion Date June 2018 P a g e 122 13138 Arctic Circle, Santa Fe Springs, CA 90670-5508 LEED Electric Inc. ■ �� `CCU ELECTRIC RFP For On -Call Electrical Repair & Rehabilitation Services LEED Electric, Inc. Statement of Qualification Project No. 6 Project Name Mesa Well Automation & Rehabilitation Location Costa Mesa, CA Owner Mesa Water District Project Manager Name Kieler Smith E-mail and Telephone No. (949) 330-4172 kielersmith@mbakerinti.com Contract Value $ 3,343,284.82 (including change orders) 5 Well Sites, Integration & Automation, (4) Variable Frequency Drives, (5) Brief Description of Firm's Scope of Motor Control Centers, (5) Switchboards, Instrumentation at all Sites, Work for the Project Flowmeters, Control Panels at all Sites, Setting of a 164 Sq Ft Prefabricated Electrical Building at Well 1. Completion Date February 2019 Project No. 7 Project Name Temescal Canyon Park Stormwater BMP Project Phase II Location Los Angeles, CA Owner City of Los Angeles Depart. Of Public Works, Bureau of Engineering Project Manager Name Waleed Azar E-mail and Telephone No. (213)272-4254 Waleed.azar@lacity.org Contract Value $ 659,143.00 (including change orders) Brief Description of Firm's Scope of Installation of new conduit, wire, instrumentation and instrument cable. Work for the Project Furnish and Install VFD, MCC Switchgear, and new Stormwater Treatment System. Completion Date August 2018 1 a = - 123 13138 Arctic Circle, Santa Fe Springs, CA 90670-5508 LEED Electric Inc. ■ �� `CCU ELECTRIC RFP For On -Call Electrical Repair & Rehabilitation Services LEED Electric, Inc. Statement of Qualification Project No. 8 Project Name Advanced Water Treatment Demonstration Facility Location Carson, CA Owner Metropolitan Water District of Southern California Project Manager Name Joe Robles,586 P.E. E-mail and Telephone No. (909)392-2 JRobles@mwdh2o.com Contract Value $4,039,000.00 (including change orders) New Ground up Advanced Water Treatment Demonstration Facility with 0.5MGD Clean Water Production. Systems installed MSR, Chemical Feed Brief Description of Firm's Scope of System, RO System, Advanced Oxidization UV. Turn Key Electrical and Work for the Project Instrumentation which included Prefabricated Electrical Building, Service Switchboard, MCC, VFD's, Main PLC (1,500 1/0's), RTU, Local Control Panels, (11) Analyzer Racks, Ammonia, PLC & SCADA, Programming, Testing, Start- up & Commissioning. Completion Date December 2019 Project No. 9 Project Name Hyperion Secondary Effluent Pump Station Improvements Location Playa Del Rey, CA Owner West Basin Municipal Water District Project Manager Name Kevin Cullen, MSCE E-mail and Telephone No. (310) 660-6259 KevinC@westbasin.org Contract Value $3.080,000.00 (including change orders) Brief Description of Firm's Scope of Furnish & Install Electrical Ductbank, Medium Voltage Switchgear, Control Work for the Project Panels, DCS System, Motor Control Center and Pumps, 4160V, Qty (2) 600A with Main -Tie -Main Circuit Breaker Completion Date January 2020 P a g e 124 13138 Arctic Circle, Santa Fe Springs, CA 90670-5508 LEED Electric Inc. L.CCY ELECTRIC RFP For On -Call Electrical Repair & Rehabilitation Services LEED Electric, Inc. Statement of Qualification Project No. 10 Project Name Venice Dual Force Main & Pumping Plant Generator Replacement Location Venice, CA Owner City of Los Angeles, Bureau of Engineering Project Manager Name Richard Southerland E-mail and Telephone No. (310)301-2109 Richard.southerland@lacity.org Contract Value $4,688,790.00 (including change orders) Brief Description of Firm's Scope of Replacement of Generators, furnish and install Instrumentation and Work for the Project Controls, Underground conduits, wire, cable and controls. Completion Date Jan. 2020 Project No. 11 Project Name Valencia Water Reclamation Plant UV Disinfection Facilities Location Valencia, CA Owner Santa Clarita Valley Sanitation District of Los Angeles County Project Manager Name JelmerTorres E-mail and Telephone No. (562) 699-7411 jtorres@lacsd.org Contract Value $3,633,922.00 (including change orders) Brief Description of Firm's Scope of Furnish and install new UV Disinfection System, infrastructure, including 2 Work forthe Project Unit Substations, MCC's VFD's, Control Panels, Instruments, Commissioning and Startup Services. Completion Date March 2021 Project No. 12 Project Name Greg Avenue Pressure Control Structure Pump Modification and New Control Building Location Sun Valley, CA Owner The Metropolitan Water District of Southern California Project Manager Name Joe Robles, P.E., (909) 392-2586, JRobles@mwdh2o.com E-mail and Telephone No. Shane Singh, (303) 995-1287, shane.ramcharansingh@stantec.com Zakir Hirani, (626) 375-6780, zakir.hirani@stantec.com Contract Value $3,539,258.00 (including change orders) New pump station building, infrastructure, including new LADWP Brief Description of Firm's Scope of Substation, MV Switchgear, MV VFD's, 4160V switchgear, 1,200AMP, Work for the Project temporary 4160V switchgear, bus duct, security system, control panels, flow meters, PLC and programming, commissioning, and startup. Completion Date Feb. 2021 P a g e 125 13138 Arctic Circle, Santa Fe Springs, CA 90670-5508 LEED Electric Inc. 27 ■ �� `CCU ELECTRIC RFP For On -Call Electrical Repair & Rehabilitation Services LEED Electric, Inc. Statement of Qualification Additional Client/Customer References Client No. 1 Client Name County of Los Angeles, Department of Public Works Contact E-mail, Telephone No. Adam Lee 900 S Fremont Ave and Address (626) 458-6185 Alhambra, CA 91803 AWLEE@dpw.lacounty.gov Client No. 2 Client Name City of Santa Ana Contact E-mail, Telephone No. Juan Ramirez (714) 647.3377 220 S. Daisy Ave and Address jramirez@santa-ana.org Santa Ana, CA 92703 Client No. 3 I Client Name Mesa Water District I Contact E-mail, Telephone No. Dustin Burnside 1965 Placentia Ave (949) 207.5466 and Address DustinB@MesaWater.org Costa Mesa, CA 92627 Client No. 4 Client Name Irvine Ranch Water District Jacob Moeder Contact E-mail, Telephone No. (949)453-5544 15600 Sand Canyon Ave and Address Moeder@IRWD.com Irvine, CA 92618 Client No. 5 Client Name City of Los Angeles, Department of Public Works Contact E-mail, Telephone No. John Hamilton 12000 Vista Del Mar and Address (310) 648-6129 Playa Del Rey, CA 90293 John.cobb.hamilton@lacity.org Client No. 6 Client Name Orange County Water District Contact E-mail, Telephone No. Ryan Bouley 18700 Ward Street, and Address (714) 378-3200 Fountain Valley, CA 92708 rbouley@ocwd.com P a g e 126 13138 Arctic Circle, Santa Fe Springs, CA 90670-5508 LEED Electric Inc. r s �� `MMLI ELECTRIC RFP For On -Call Electrical Repair & Rehabilitation Services LEED Electric, Inc. Statement of Qualification Client No. 7 Client Name City of Santa Monica Contact E-mail, Telephone No. Deborah McCloskey 2500 Michigan Avenue (310) 458.2201 and Address Deborah. McCloskey@SMGOV.NET Santa Monica, CA 90404 Client No. 8 Client Name Water Replenishment District (WRD) of Southern California Contact E-mail, Telephone No. Tom Knoell 4040 Paramount Blvd. and Address (562) 275.4266 Lakewood, CA 90712 tknoell@wrd.org Client No. 9 Client Name City of Santa Ana Contact E-mail, Telephone No. Cesar E. Barrera, P.E.(714) 6473387 220 S. Daisy Ave . and Address Santa Ana, CA 92703 cbarrera@santa-ana.org Client No. 30 Client Name J.F. Shea Construction Contact E-mail, Telephone No. Ray Watford(909) 595-4397 667 Brea Canyon Road, Suite 30 and Address ray.watford@jfshea.com Walnut, CA 91788-0489 Client No. 11 Client Name Pacific Hydrotech Corporation Contact E-mail, Telephone No. Ozzie Garibaldo 314 E. 3rd St. (951) 943-8803 and Address ozzie@pachydro.com Perris, CA 92570 Client No.12 Client Name RSH Construction Bob Hamilton Contact E-mail, Telephone No. 3883 Wentworth Drive (951) 925-2288 and Address bhamilton@rshconstruction.com Hemet, CA 92545 P a g e 127 13138 Arctic Circle, Santa Fe Springs, CA 90670-5508 LEED Electric Inc. ■ �� `CCU ELECTRIC RFP For On -Call Electrical Repair & Rehabilitation Services LEED Electric, Inc. Statement of Qualification Client No. 13 Client Name Schuler Engineering Contact E-mail, Telephone No. Brian Sohl 564 Bateman Circle (951) 738-9215 and Address brian@schulerengineering.com Corona, CA 92880 Client No. 14 Client Name SS Mechanical Construction Corp. Contact E-mail, Telephone No. John Whelan 26561 Jacinto Drive and Address (714)847-1317 Mission Viejo, CA 92692 John@ssmechanica1.com Client No. 15 Client Name PPC Construction, Inc. Contact E-mail, Telephone No. Samuel P. Hannah (323) 256-2600 930 Colorado Blvd., Suite 3 and Address samuel.hannah@ppcco.net Los Angeles, CA 90041 P a E e 128 13138 Arctic Circle, Santa Fe Springs, CA 90670-5508 LEED Electric Inc. r 0 �� `MMLP ELECTRIC RFP For On -Call Electrical Repair & Rehabilitation Services LEED Electric, Inc. Statement of Qualification T&M Labor Rates & T&M Cost Proposal Sample P a a e 1 29 13138 Arctic Circle, Santa Fe Springs, CA 90670-5508 LEED Electric Inc. z j � 2 j w \ © a W $ J 2 A W \ FPI ( 89 2 � LLI 2 LU k _ § LU of / - - \ ! 0 x - - <! | § | [ ww \ LIL ] § ! ! 2 w / ! —Ili `CCY ELECTRIC Estimate Proposal and Change Order Form LEED ELECTRIC INC. 13138 Arctic Circle Santa Fe Springs, CA 90670 TEL: (562) 270-9500 www.leedelertrir ram Project: On -Call Electrical Repair&Rehab Services LEI CE# TEXXXXX-XXX DATE: XX/XX/XXXX Contract: TXX-XXX FIR It LOCAL: 11 Customer: City of Santa Ana CD/DOC# ESTIMATOR: AS Description of "SAMPLE - Work: 1. Material 1 . Material (See attached detail sheet) $ 2 . Quoted Material & Services (See attached vendor quotes) $ - 3 . Allowance Miscellaneous Material/Consumables/Small Tools 0.00% of Line 1 &2 $ 4. Subtotal- 5 . Sales Tax at applicable rate 10.50% of Line4 $ - 6 . Shipping and Handling $ - 7. Total Material Cost: $ U. Field Labor Regular Time Over Time x1.5 Over Time x2.0 8a. Electrician Labor Man Hours (see attached detail sheet) 0.00 hrs 0.00 hrs 0.00 hrs Bb. Job Factor 0.00 hrs 0.00 hrs 0.00 hrs Bc. Electrician Labor Efficiency Factor 0.00 hrs 0.00 hrs 0.00 hrs Ed .Safety 0.00 hrs 0.00 hrs 0.00 hrs Be. Clean-up 0.00 hrs 0.00 hrs 0.00 hrs Elf. As -Built Drawings 0.00 hrs 0.00 hrs 0.00 hrs Big. TOTAL ESTIMATED DIRECT LABOR MH(8a thru Bf) 0.00 hrs 0.00 hrs 0.00 hrs 9. Journeyman hours (from 8g above -Regular Time) 0.00 hrs@ $103.61 /hour $ - 9a. Journeyman hours (from BE above-OT 1.Sx) 0.00 furs @ $138.33 Jhour $ - 91b. Journeyman hours (from Sg above-OT 2.Ox) 0.00 hrs@ $173.06 /hour $ - 10. Electrician GF/FM (Regular Time) 0.00 hrs @ $121.93 /hour $ 10a. Electrician GF/FM (Over Time 1.5x) 0.00 hrs @ $165.40 /hour $ 10b. Electrician GF/FM (Over Time 2.Ox) 0.00 hrs @ $208.90 /hour $ - 11.Helper/Apprentice (Regular Time) 0.00 hrs@ $81.59 /hour $ - 12a. Helper/Apprentice (Over Time l.Sx) 0.00 hrs@ $107.65 /hour $ - 12b. Helper/Apprentice (Over Time 2.0x) 0.00 firs @ $133.69 /hour $ 13 . Total Direct Labor 9 thru 12 0.00 $ 14. Allowance Miscellaneous Material/Consumables/Small Tools 0.00% $ - 15.Overtime Expense from attached Schedule if applicable. 16. TOTAL LABOR COST: $ III. DIRECT JOB EXPENSE 17. Truck w/tools 0.00 hrs @ $28.46 /hour $ - 18. Bending/Threading Trailer 0.00 hrs @ $14.56 /hour $ - 19. Power Generator (under 1OKW) 0.00 hrs @ $4.66 /hour $ - 20. Forklift 0.00 hrs @ $500.00 /Week $ - 21 . Gradall 0.00 hrs @ $950.00 /Week $ - 22. Project Manager/Design Consult/Fabrication 0.00 hrs @ $125.00 /hour $ - 23 . Make Copies of Prints $0.00 $ - 24. Rented/Owned Tools & Equipment (See attached Equipment list) $ - 25. Allowance Miscellaneous Material/Consumables/Small Tools 0,00% $ - 26.TOTAL EXPENSES: $ IV. OVERHEAD AND PROFIT 27. Material $ - 28. Material Markup 15.0% of line 27 $ 29. Field Labor $ - 30.Field Labor Markup 20.0% of line 29 $ 31. Oirect lob Expense $ - 32 . Direct Job Expense Markup 15.0% of line 31 $ 33 . Subcontract (See attached subcontractor quotes) $ - 34. Subcontract markup 15.0% of line 33 $ 35 . Totals of Line 27 through 34 $ 36 . Extended Overhead Breakdown (see attached Breakdown sheet) $ - 37 . Inefficiency Costs (see attached worksheet) $ - 38 .Subtotal $ 39. Bond Adder 0.00% of line 38 $ - 40. TOTAL FOR THIS ESTIMATE V. EXTENSION OF TIME REQUIRED: X Working Days Based on X men crew Note: This Pricing is valid for 14 calendar days ■ �� LMMMLI1 ELECTRIC LIC. # 379096 C70, A Power, Control and Instrumentation Contractor Since 1979 MEMBER OF THE NATIONAL ELECTRICAL CONTRACTORS ASSOCIATION CITY OF SANTA ANA RFP ON -CALL ELECTRICAL REPAIR AND REHABILITATION SERVICES RFP NO.: 21-122 November 16, 2021 at 4:OOPM LEED ELECTRIC INC. • 13138 ARCTIC CIR • SANTA FIE SPRINGS, CA 90670-5508 • (562) 270.9500 TEL • (562) 863.5723 FAX • WWW.LEEDELECTRIC.COM CITY OF SANTA ANA RFP NO.: 21-122 ON -CALL ELECTRICAL REPAIR AND REHABILITATION SERVICES APPENDIX ATTACHMENT 2: FEE PROPOSAL Certification - I certify that I have read, understand and agree to the terms and conditions of this Request for Proposal. I have examined the ATTACHMENT 1: SCOPE OF WORK. I am familiar with all the existing conditions and limitation that may impact work requests. I understand and agree that I am responsible for reporting any errors, omissions or discrepancies to the City for clarification prior to the submission of my proposal. Proposer shall submit hourly rates schedule, which shall include but not limited to, direct and indirect costs for labor, for staff per job classification, material, equipment rates, overhead, incidental supplies, travel, mileage, and fuel. Any special materials will be purchased by the contractor only after discussed and authorized by the City projects manager or designee in writing. Prior to commencement of services, Contractor shall provide separate quotes, upon request by the City, which shall be approved by the City's Public Works Water Resources Division. FEE SCHEDULE The undersigned declares that he/she has carefully examined the request for proposal, that he/she has examined the Proposed Scope of Services, and hereby proposes to furnish all material and do all the work required to complete the said work in accordance with said Proposed Scope of Services, for the unit price(s) set forth in the following schedule: Note: This contract is subject to prevailing wages. TO: CITY COUNCIL OF THE CITY OF SANTA ANA FROM: LEED Electric, Inc. Item # Bid Item Unit Quantity Amount well 32 Electrical Rehabilitation 1. Electrical Conduit LS 1 $ 116,200 2. Building and Site Electrical System LS 1 $ 130,687 3. VFD Motor Control Center LS 1 $ 78,000 4. Automatic Transfer Switch LS 1 $ 18,000 5. Instrumentation and Control Equipment LS 1 $ 72,000 6. Building Lighting LS 1 s 21,960 7 Electrical Equipment and Facilities Chemical Building) LS 1 $ 47,000 City of Santa Ana RI=P 21-122 On -Call Electrical Repair and Rehabilitation Services Page 20 CITY OF SANTA ANA RFP NO.: 21-122 ON -CALL ELECTRICAL REPAIR AND REHABILITATION SERVICES 8 Instrumentation and Control Equipment Chemical Building) LS 1 $ 68,000 9. Building Lighting (Chemical Building) LS 1 $ 14,880 10. Fiber Optics Conduits (3" Conduits) LF 3,900 $198,900 11. Fiber Optic Pull Box EA 8 $ 46,400 12. Mobilization/Demobilization LS 1 $ 40,000 13. Commissioning and Training EA 1 $ 25,000 14 As Built Plans, O&M Manuals and Warranties LS 1 $ 10,000 Total $ 887.027 idule. Contractors tabor and equipment rate sheet shall list rates equipment and materials. BIDDER INFORMATION: Legal Company Name: LEED Electric, Inc. Complete address: 13138 Arctic Circle, Santa Fe Springs. CA 90670 Phone Number: (562) 270-9500 Email Address: Authorized Sigm Name: Seved A. Jamali Dinan Title: Chief Executive Officer City of Santa Ana RFP 21-122 On -Call Electrical Repair and Rehabilitation Services Page 21 CITY OF SANTA ANA RFP NO.: 21-122 ON -CALL ELECTRICAL REPAIR AND REHABILITATION SERVICES APPFNDIX --- - ------- ATTACHMENT 3: PROPOSER'S REFERENCES List and describe fully the contracts performed by your firm which demonstrate your ability to provide the supplies, equipment or services included in the scope of the proposal specifications. Attach additional pages if required. The City reserves the right to contact each of the references listed for additional information regarding your firm's qualifications. Reference Customer Name: City of Santa Ana Address: 215 S. Center Street Santa Ana. CA 92703 Contract Amount: 676,673.00 Contact Individual Cesar Barrera cbarreraOsanta-ana.org Phone Number: 714-647-3387 Facsimile Number: N/A Year: 2017-2021 Description of supplies, equipment, or services provided: Electrical maintenance, repair, troubleshooting, installation at city pump stations. installation of holiday lighting Reference Customer Name: Los Angeles County Public Work�_ontact Individual: Adam Lee awleeta'�dpw.lacounty.gov Address: 900 S. Fremont Ave. Phone Number: 626-458-6185 Alhambra, CA 91803 Facsimile Number: N/A Contract Amount: 727,272 OD Year: 2019-Present Description of supplies, equipment, or services provided: Electrical and Instrumentation Services and Maintenance on LA County's 100+ Seawater Barrier Injection and Observation Wells in Wilmington Redondo BParh and I nng Rpnrh Arpac cinro 9131'2 Reference Customer Name: M -ca WQ atPr District Address: 1965 Placentia Ave. Costa Mesa, CA 92627 Contact Individual: Dustin Burnside dustinb ara)mesawater.org Phone Number: 949-207-5466 Facsimile Number: N/A Contract Amount: 100,000.00 Year: 201 R-Prasant Description of supplies, equipment, or services provided: Electrical maintenance repair, troubleshooting. Jiahting femn(� raQj nnwar installation at agonCy operated pump stations City of Santa Ana RFP 21-122 On -Call Electrical Repair and Rehabilitation Services Page 22 CITY OF SANTA ANA RFP NO.: 21-122 ON -CALL ELECTRICAL REPAIR AND REHABILITATION SERVICES Reference Customer Name: City of Santa Monica Contact Individual:Tim Vosecky tim.vosecky@santamonica.gov Address: 2500 Michigan Ave. Bldg 1 Santa Monica, CA 90404 Phone Number: 310-458-2201 Facsimile Number. N/A Contract Amount: 1,660,000.00 Year: Description of supplies, equipment, or services provided: Electrical Installation, Service, Troubleshootini 2018-Present THIS FORM MUST BE COMPLETED AND INCLUDED WITH THE PROPOSAL. PROPOSALS THAT DO NOT CONTAIN THIS FORM WILL BE CONSIDERED NONRESPONSIVE. City of Santa Ana RFP 21-122 On -Call Electrical Repair and Rehabilitation Services Page 23 CITY OF SANTA ANA RFP NO.: 21-122 ON -CALL ELECTRICAL REPAIR AND REHABILITATION SERVICES NON -COLLUSION AFFIDAVIT (Title 23 United States Code Section 112 and Public Contract Code Section 7106) In conformance with Title 23 United States Code Section 112 and Public Contract Code 7106 the BIDDER declares that the bid is not made in the interest of, or on behalf of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham; that the BIDDER has not directly or indirectly induced or solicited any other BIDDER to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any BIDDER or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the BIDDER has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price of the BIDDER or any other BIDDER, or to fix any overhead, profit, or cost element of the bid price, or of that of any other BIDDER, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the BIDDER has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay, any fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. Note: The above Non -collusion Affidavit is part of the Proposal. BIDDERS are cautioned that making a false certification may subject the certifier to criminal prosecution., Signed State of California Co�of Subscribed an2hs by be the person(s) v to (or affirmed) before me on this day of , 20_, �— proved to me on the basis of satisfactory evidence to onerred before me Notary Public Signature NotaN-Rublic Seal Sam CM0_ .dU_C� City of Santa Ana RFP 21-122 On -Call Electrical Repair and Rehabilitation Services Page 34 CALIFORNIA JURAT GOVERNMENT CODE § 8202 A notary public or other officer completing this certificate verifies only the Identity of the individual who signed the document to which this certificate Is attached, and not the truthfulness, accuracy, or validity of that document, State of California Countyof Los Angeles ANNErrE IRIBARREN Notary public - California Los Angeles County Commission x 2228985 OMY Comm. Expires Mar 25, 2023 Place Notary Seal and/or Stomp Above Subscribed and sworn to (or affirmed) before me on this 12th day of November 2021 , by Date Month Year (1) Seyed A. Jamali-Dinan (and (2) Norne(s) of Signer(s) proved to me on the basis of satisfactory evidence to be the person(s) who appeared before me. Signature bd.-°v.�s-.--� Signature of Notary Public A bT1AT1 A 1 Completing this information can deter alteration of the document ar fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: Signer(s) Other Than Named Above: Number of Pages: .. ,fY):e +"....- .Si&::.! FS;n.,IF (r.}} Efl[ii °1F al .tcn.I'.nfVir x,l.r ; rill" ,t6..< tYf"r:,Yx-- ... elra d6.�.s. »Sfl+P„k�!?' ti.,rbl.�.&?-f.5n". �5°fS$id 02019 National Notary Association CITY OF SANTA ANA RFP NO.: 21-122 ON -CALL ELECTRICAL REPAIR AND REHABILITATION SERVICES NON-DISCRIMINATION CERTIFICATION The undersigned consultant or corporate officer, during the performance of this contract, certifies as follows: 1. The Consultant shall not discriminate against any employee or applicant for employment because of race, color, religion, sex, or national origin. The Consultant shall take affirmative action to ensure that applicants are employed, and that employees are treated during employment without, regard to their race, color, religion, sex, or national origin. Such action shall include, but not be limited to, the following: employment, upgrading, demotion, or transfer; recruitment or recruitment advertising; layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship. The Consultant agrees to post in conspicuous places, available to employees and applicants for employment, notices to be provided setting forth the provisions of this nondiscrimination clause. 2. The Consultant shall, in all solicitations or advertisements for employees placed by or on behalf of the Consultant, state that all qualified applicants will receive consideration for employment without regard to race, color, religion, sex, or national origin. 3. The Consultant shall send to each labor union or representative of workers with which he/she has a collective bargaining agreement or other contract or understanding, a notice to be provided advising the said labor union or workers' representatives of the Consultant's commitments under this section, and shall post copies of the notice in conspicuous places available to employees and applicants for employment. 4. The Consultant shall comply with all provisions of Executive Order 11246 of September 24, 1965, and of the rules, regulations, and relevant orders of the Secretary of Labor. 5. The Consultant shall furnish all information and reports required by Executive Order 11246 of September 24, 1965, and by rules, regulations, and orders of the Secretary of Labor, or pursuant thereto, and will permit access to his/her books, records, and accounts by the administering agency and the Secretary of Labor for purposes of investigation, to ascertain compliance with such rules, regulations, and orders. 6. In the event of the Consultant's non-compliance with the nondiscrimination clauses of this contract or with any of the said rules, regulations, or orders, the contract may be canceled, terminated, or suspended in whole or in part and the Consultant may be declared ineligible for further Government contracts or federally assisted construction contracts in accordance with procedures authorized in Execution Order 11246 of September 24, 1965, and such other sanctions may be imposed and remedies invoked as provided in Executive Order 11246 of September 24, 1965, or by rule, regulations, or order of the Secretary of Labor, or as otherwise provided by law. City of Santa Ana RFP 21-122 On -Call Electrical Repair and Rehabilitation Services Page 36 CITY OF SANTA ANA RFP NO.: 21-122 ON -CALL ELECTRICAL REPAIR AND REHABILITATION SERVICES 7. The Consultant shall include the portion of the sentence immediately preceding paragraph (1) and the provisions of paragraphs (1) through (7) in every subcontract or purchase order unless exempted by rules, regulations, or orders of the Secretary of Labor issued pursuant to Section 204 of Executive Order 11246 of September 24, 1965, so that such provisions will be binding upon each subcontract or purchase order as the administering agency may direct as means of enforcing such provisions, including sanctions for noncompliance; provided, however, that in the event the Consultant becomes involved in, or is threatened with, litigation with a subconsultant or vendor as a result of such direction by the administering agency, the Consultant may request that the United States enter into such litigation to protect the interests of the United States. 8. Pursuant to California Labor Code Section 1735, as added by Chapter 643 Stats. 1939, and as amended, no discrimination shall be made in the employment of persons upon public works because of race, religious creed, color, national origin, ancestry, physical handicaps, mental condition, marital status, or sex of such persons, except as provided in Section 1420, and any consultant of public works violating this Section is subject to all the penalties imposed for a violation of the Chapter. / Signed: Title: Chief Executive Firm: LEED Electric Inc. Date: 11 /16/2021 City of Santa Ana RFP 21-122 On -Call Electrical Repair and Rehabilitat on Services Page 37 CITY OF SANTA ANA RFP NO.: 21-122 ON -CALL ELECTRICAL REPAIR AND REHABILITATION SERVICES NON -LOBBYING CERTIFICATION The prospective participant certifies, by signing and submitting this bid or proposal, to the best of his or her knowledge and belief, that: (1) No Federal appropriated funds have been paid or will be paid, by or on behalf of the undersigned, to any person for influencing or attempting to influence an officer or employee of any Federal agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with the awarding of any Federal contract, the making of any Federal grant, the making of any Federal loan, the entering into of any cooperative agreement, and the extension, continuation, renewal, amendment, or modification of any Federal contract, grant, loan, or cooperative agreement. (2) If any funds other than Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any Federal agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with this Federal contract, grant, loan, or cooperative agreement, the undersigned shall complete and submit Standard Form-LLL, "Disclosure of Lobbying Activities," in conformance with its instructions. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Submission of this certification is a prerequisite for making or entering into this transaction imposed by Section 1352, Title 31, U.S. Code. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The prospective participant also agrees by submitting his or her bid or proposal that he or she shall require that the language of this certification be included in all lower tier subcontracts, which exceed $100,000 and that all such subrecipients shall certify and disclose accordingly. Signed: Title: Chief Executive Officer Firm: LEED Electric, Inc. Date: 11/1 City of Santa Ana RFP 2'i -1 2_2 On -Call Electrical Repair and Rehabilitation Services Page 35 Francine R. Digitally signed by Francine R. Villareal Villareal Date: 2022.02.24 104s 19-DR'00' d'is CERTIFICATE OF LIABILITY INSURANCE DATE(MMIODrIYYY) ovamzosz THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the Certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER ADD Risk Insurance Services West, Inc. Los Angeles CA officeINC. coNT AME:Acr PHONE (866) 283-7122 FaX (800) 363-010$ No. Eat): uc. xo.: 707 Wilshire Boulevard Suite 2600 E+aAIL ADDRESS: Los Angeles CA 90017-0460 USA INSURERS) AFFORDING COVERAGE NAIC# INSURED INSURERA: Zurich American Ins Co 16535 Heed Electric, Inc. 13138 Arctic Circle Santa Fe Springs CA 90670 USA INSURER B: RSUI indemnity company 22314 INSURERC: American Guarantee & Liability Ins Cc 26247 INSURERD: Crum & Forster Specialty insurance Co. 44520 INSURER E: Bee COVERAGES CFRTIFICATF NIIIII 57ooQ15FARAQ Rcul'Urim MUNsnco. THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERM$ EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. Limits shown are as re uested INSR TYPE OF INSURANCE ADOL BUBR POLICYNUMBER POLICY EFF 10/01/2021 POLICY UP LIMITS A GENERAL LIABILITY Y Y 6L0323075803 10 0 2 EACH OCCURRENCE $1,000,000 CIAIMS-MADE xI OCCUR DAMAGE TO RENTEDcurtence P ESEaoc $300,000 TXCONIMERCIAL MED EXP(my one person) $S,000 PERSONAL& AOV INJURY $1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER GENERAL AGGREGATE $2,500,000 POLICY X PRO x Lee JECT PRODUCTS-COMPIOP AGG $2,000, 000 OTHER: A AUTOMOBILELIASIUTY Y Y BAP 3230759 - 03 10/01/20211010112022 COMBINED SINGLE LIMIT g1, 000, 000 BODILY INJURY ( Per person) AINY AUTO OWNED SCHEDULED BODILY INJURY (Per axident) AUTOS ONLY AUFOS HINEDAUTOS NON -OWNED PROPERTY DAMAGE ONLY AUTOS ONLY Perarodenl CompJColl. Ded. $2 , SOO G X UNKUELLALIAB X OCCUR AUC324371203 10/01/2021 10/01/2022 EACHOCCURRENCE $S'Lin H. EXCESS LIAB CLAIMS -MADE AGGREGATE $51000,000 OED RETENTION A WORMERSCOMPENSATIONAND Y wc324371103 10/01/2021 10/01/2022 X I PER STATUTE oTH EMPLOYERS' LIABILITY El EACH ACCIDENT $1,000,000 ANY PROPRIETOR I PARTNER I EXECUTIVE N OFFICEWMEMBER ERCLUDEDi NIP E.L. DISEASE -EA EMPLOYEE $1,000,000 (Mandab,y In NH) DESCRIPTION OF OPERATIONS be. E.L. DISEASE -POLICY LIMIT $1,000,000 D Env Contr Poll PKC112160 10/01/2021 10/01/2022 Each POLL Condition $2,000,000 Claims made Deductible $10,000 Aggregate Limit $3,000,000 DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached Nmom space is required) city of Santa Ana, its officers, employees, volunteers, agents and representatives are included as Additional insured in accordance with the policy provisions of the General Liability and Automobile Liability policies. General Liability policy evidenced herein is Primary and Non -Contributory to other insurance available to Additional Insured, but only in accordance with the policy's provisions. A waiver of subrogation is granted in favor of Certificate Holder in accordance with the policy provisions of the General Liability, Automobile Liability and Workers' Compensation policies. 0 m `a w t M Is T1 0 CERTIFICATE HOLDER CANCELLATION eak SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POUCYPROVISIONS. Cit Of Santa Ana AUTHORQED REPRESENTATIVE Risk Management Division 20 Civic Center Plaza, 4th Floor Santa Ana CA 92701 USA L�//��''��//{{•�� Mn alLtlJYR�1�d/LfRlgLki ©1988-2015 ACORD ACORD 25 (2016103) The ACORD name and logo are registered marks of ACORD //REVIEwEC&APPRavi r��4,"Hisk .! D vj&4 C Risk Management Analyst AGENCY CUSTOMER ID: 570000069943 LOC #: A� ADDITIONAL REMARKS SCHEDULE Page of AGENCY AGO Risk Insurance Services west, Inc. NAMED INSURED Leed Electric, Inc. POLICYNUMBER see Certificate Number: 570091564849 CARRIER See Certificate Number: 570091564849 NAIC CODE EFFECTIVE DATE ADDITIONAL REMARKS THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM, FORM NUMBER: ACORD 25 FORM TITLE: Certificate of Liability Insurance INSURER(S) AFFORDING COVERAGE NAIC It INSURER INSURER INSURER INSURER ADDITIONAL POLICIES If a policy below does not include limit information, refer to the corresponding policy on the ACORD certificate form for policy limits. IUR IIII TYPE OF INSURANCE ADDL INSD SUBR WVD POLICVNUMBER POLICY EFFECTIVE DATE >IMIDDNVYY POLICY ERPIRATIOY DATE MMIDD/1' Llhll'f5 EXCESS LIABILITY B NHA252429 10/01/2021 10/01/2022 Aggregate $5,000,000 OTHER D Env Contr Prof PKC112160 claims Made 10/01/2021 10/01/2022 Each Act $2,000,000 Deductible $10,000 ACORD 101 (2008/01) The ACORD name and logo are registered marks of ACORD RE%AEWM & APPROVED Br 02008A RidcMRnBgcmtmtDivisiDn ®' Risk Management Analyst AGENCY CUSTOMER ID: 570000069943 LOC #: ADDITIONAL REMARKS SCHEDULE Pace of AGENCY Aon Risk Insurance Services West, Inc. NAMED INSURED Leed Electric, Inc. POLICYNUMBER See certificate Number: 570091564849 CARRIER See Certificate Number: 570091564849 I NAIL CODE EFFECTIVE DATE: ADDITIONAL REMARKS THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM, FORM NUMBER: ACORD 25 FORM TITLE: Certificate of Liability Insurance Excess Liability Policy # MXL0431782 Policy term : 10/1/2021 to 10/1/2022 underwriter company name • Mt. Hawley Insurance Company Each Occurrence $ 5,000,000 Aggregate $5,000,000 Policy # PuB786667 Policy term : 10/1/2021 to 10/1/2022 underwriter company name: Tokio Marine specialty insurance Each Occurrence 10,000,000 General Aggregate 10,000,000 ACORD 101 (2008/01) w matugemaaunvwl i [REoemm 6 AP ® ,PIROvBY: 02008 ACORD CORPORATION. The ACORD name and logo are registered marks of ACORD :®l RI$k MdDa9PRH'O[ Analyst Additional Insured —Automatic — Owners, Lessees Or Contractors 0 ZURICH Policy No. Eff. Date of Pol. Exp. Date of Pol. I Eff. Date of End. I Producer No. Add]. Prom Return Prem. LO-3230758-03 10/01 /2021 10/01/2022 10/01 /2021 75272000 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. Named Insured: Address (including ZIP Code): Leed Electric, Inc. 13138 Arctic Circle Santa Fe Springs, CA 90670 This endorsement modifies insurance provided under the: Commercial General Liability Coverage Part A. Section II — Who Is An Insured is amended to include as an additional insured any person or organization whom you are required to add as an additional insured on this policy under a written contract or written agreement. Such person or organization is an additional insured only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by: 1. Your acts or omissions; or 2. The acts or omissions of those acting on your behalf, in the performance of your ongoing operations or "your work" as included in the "products -completed operations hazard", which is the subject of the written contract or written agreement. However, the insurance afforded to such additional insured: 1. Only applies to the extent permitted by law; and 2. Will not be broader than that which you are required by the written contract or written agreement to provide for such additional insured. B. With respect to the insurance afforded to these additional insureds, the following additional exclusion applies: This insurance does not apply to: "Bodily injury", "property damage" or "personal and advertising injury" arising out of the rendering of, or failure to render, any professional architectural, engineering or surveying services including: a. The preparing, approving or failing to prepare or approve maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawings and specifications; or b. Supervisory, inspection, architectural or engineering activities. This exclusion applies even if the claims against any insured allege negligence or other wrongdoing in the supervision, hiring, employment, training or monitoring of others by that insured, if the "occurrence" which caused the "bodily injury" or "property damage", or the offense which caused the "personal and advertising injury", involved the rendering of or the failure to render any professional architectural, engineering or surveying services. e. Risk Mm ganaiLDividw' REVIEWm 6 APPRO Eh- 3 �& Risk Management Analyst Includes copyrighted material of Insurance Services Office, Inc., with its permission. C. The following is added to Paragraph 2. Duties In The Event Of Occurrence, Offense, Claim Or Suit of Section IV — Commercial General Liability Conditions: The additional insured must see to it that: 1. We are notified as soon as practicable of an "occurrence" or offense that may result in a claim; 2. We receive written notice of a claim or "suit' as soon as practicable; and 3. A request for defense and indemnity of the claim or "suit' will promptly be brought against any policy issued by another insurer under which the additional insured may be an insured in any capacity. This provision does not apply to insurance on which the additional insured is a Named Insured if the written contract or written agreement requires that this coverage be primary and non-contributory. D. For the purposes of the coverage provided by this endorsement: 1. The following is added to the Other Insurance Condition of Section IV — Commercial General Liability Conditions: Primary and Noncontributory insurance This insurance is primary to and will not seek contribution from any other insurance available to an additional insured provided that: a. The additional insured is a Named Insured under such other insurance; and b. You are required by written contract or written agreement that this insurance be primary and not seek contribution from any other insurance available to the additional insured. 2. The following paragraph is added to Paragraph 4.b. of the Other Insurance Condition of Section IV — Commercial General Liability Conditions: This insurance is excess over: Any of the other insurance, whether primary, excess, contingent or on any other basis, available to an additional insured, in which the additional insured on our policy is also covered as an additional insured on another policy providing coverage for the same "occurrence", offense, claim or "suit'. This provision does not apply to any policy in which the additional insured is a Named Insured on such other policy and where our policy is required by a written contract or written agreement to provide coverage to the additional insured on a primary and non- contributory basis. E. This endorsement does not apply to an additional insured which has been added to this policy by an endorsement showing the additional insured in a Schedule of additional insureds, and which endorsement applies specifically to that identified additional insured. F. With respect to the insurance afforded to the additional insureds under this endorsement, the following is added to Section III — Limits Of Insurance: The most we will pay on behalf of the additional insured is the amount of insurance: 1. Required by the written contract or written agreement referenced in Paragraph A. of this endorsement; or 2. Available under the applicable Limits of Insurance shown in the Declarations, whichever is less. This endorsement shall not increase the applicable Limits of Insurance shown in the Declarations. All other terms and conditions of this policy remain unchanged. s< RI91Mv.gensedDivietan ReAesm 6 APPROv® By: Includes copyrighted material of Insurance Services Office, Inc., with its permission. Risk Management Analyst POLICY NUMBER: GLO-3230758-03 COMMERCIAL GENERAL LIABILITY CG 24 04 05 09 WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART SCHEDULE Name Of Person Or Organization: Any Person or Organization that requires You to waive your Rights of Recovery, in a written contract or agree- ment with the Named Insured that is executed prior to the accident or loss. The following is added to Paragraph 8. Transfer Of Rights Of Recovery Against Others To Us of Section IV —Conditions: We waive any right of recovery we may have against the person or organization shown in the Schedule above because of payments we make for injury or damage arising out of your ongoing operations or "your work" done under a contract with that person or organization and included in the "products - completed operations hazard". This waiver applies only to the person or organization shown in the Schedule above. CG 24 04 05 09 © Insurance Services Office, Inc., 2008 Wolters Kluwer Pinand RIAMmagm EDaision REMEWED&APPROVEDBY: �'. ® Risk Management Analyst Coverage Extension Endorsement 0 ZURICH Policy No. Eff. Date of Pol. Exp. Date of Pol. Eff. Date of End. I Producer No. AddT Prom Return Prem. BAP-3230759-03 10/01/2021 10/01/2022 10/01/2021 75272000 -------------- ------------- THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. This endorsement modifies insurance provided under the: Business Auto Coverage Form Motor Carrier Coverage Form A. Amended Who Is An Insured 1. The following is added to the Who Is An Insured Provision in Section II —Covered Autos Liability Coverage: The following are also "insureds": a. Any "employee" of yours is an "insured" while using a covered "auto" you don't own, hire or borrow for acts performed within the scope of employment by you. Any "employee" of yours is also an "insured" while operating an "auto" hired or rented under a contract or agreement in an "employee's" name, with your permission, while performing duties related to the conduct of your business. b. Anyone volunteering services to you is an "insured" while using a covered "auto" you don't own, hire or borrow to transport your clients or other persons in activities necessary to your business. c. Anyone else who furnishes an "auto" referenced in Paragraphs A.1.a. and A.1.b. in this endorsement. d. Where and to the extent permitted by law, any person(s) or organization(s) where required by written contract or written agreement with you executed prior to any "accident", including those person(s) or organization(s) directing your work pursuant to such written contract or written agreement with you, provided the "accident" arises out of operations governed by such contract or agreement and only up to the limits required in the written contract or written agreement, or the Limits of Insurance shown in the Declarations, whichever is less. 2. The following is added to the Other Insurance Condition in the Business Auto Coverage Form and the Other Insurance — Primary and Excess Insurance Provisions Condition in the Motor Carrier Coverage Form: Coverage for any person(s) or organization(s), where required by written contract or written agreement with you executed prior to any "accident", will apply on a primary and non-contributory basis and any insurance maintained by the additional "insured" will apply on an excess basis. However, in no event will this coverage extend beyond the terms and conditions of the Coverage Form. B. Amendment —Supplementary Payments Paragraphs a.(2) and a.(4) of the Coverage Extensions Provision in Section II — Covered Autos Liability Coverage are replaced by the following: (2) Up to $5,000 for the cost of bail bonds (including bonds for related traffic law violations) required because of an "accident" we cover. We do not have to furnish these bonds. (4) All reasonable expenses incurred by the "insured" at our request, including actual loss of earnings up to $500 a day because of time off from work. Rk1Meu9anadDMsIan REvEwm&APPRovaJar; �� Risk Management AnalystIncludes copyrighted material of Insurance Services Office, Inc., with its permission. C. Fellow Employee Coverage The Fellow Employee Exclusion contained in Section II — Covered Autos Liability Coverage does not apply. D. Driver Safety Program Liability and Physical Damage Coverage 1. The following is added to the Racing Exclusion in Section 11— Covered Autos Liability Coverage: This exclusion does not apply to covered "autos" participating in a driver safety program event, such as, but not limited to, auto or truck rodeos and other auto or truck agility demonstrations. 2. The following is added to Paragraph 2. in the Exclusions of Section III — Physical Damage Coverage of the Business Auto Coverage Form and Paragraph 2.b. in the Exclusions of Section IV — Physical Damage Coverage of the Motor Carrier Coverage Form: This exclusion does not apply to covered "autos" participating in a driver safety program event, such as, but not limited to, auto or truck rodeos and other auto or truck agility demonstrations. E. Lease or Loan Gap Coverage The following is added to the Coverage Provision of the Physical Damage Coverage Section: Lease Or Loan Gap Coverage In the event of a total "loss" to a covered "auto", we will pay any unpaid amount due on the lease or loan for a covered "auto", less: a. Any amount paid under the Physical Damage Coverage Section of the Coverage Form; and b. Any: (1) Overdue lease or loan payments at the time of the "loss"; (2) Financial penalties imposed under a lease for excessive use, abnormal wear and tear or high mileage; (3) Security deposits not returned by the lessor; (4) Costs for extended warranties, credit life insurance, health, accident or disability insurance purchased with the loan or lease; and (5) Carry-over balances from previous leases or loans. F. Towing and Labor Paragraph A.2. of the Physical Damage Coverage Section is replaced by the following: We will pay up to $75 for towing and labor costs incurred each time a covered "auto" of the private passenger type is disabled. However, the labor must be performed at the place of disablement. G. Extended Glass Coverage The following is added to Paragraph A.3.a. of the Physical Damage Coverage Section: If glass must be replaced, the deductible shown in the Declarations will apply. However, if glass can be repaired and is actually repaired rather than replaced, the deductible will be waived. You have the option of having the glass repaired rather than replaced. H. Hired Auto Physical Damage — Increased Loss of Use Expenses The Coverage Extension for Loss Of Use Expenses in the Physical Damage Coverage Section is replaced by the following: Loss Of Use Expenses For Hired Auto Physical Damage, we will pay expenses for which an "insured" becomes legally responsible to pay for loss of use of a vehicle rented or hired without a driver under a written rental contract or written rental agreement. We will pay for loss of use expenses if caused by: Ride MeugementDisimm Risk Management Analyst Includes copyrighted material of Insurance Services Office, Inc., with its permission. (1) Other than collision only if the Declarations indicate that Comprehensive Coverage is provided for any covered "auto" (2) Specified Causes Of Loss only if the Declarations indicate that Specified Causes Of Loss Coverage is provided for any covered "auto" or (3) Collision only if the Declarations indicate that Collision Coverage is provided for any covered "auto'. However, the most we will pay for any expenses for loss of use is $100 per day, to a maximum of $3000. I. Personal Effects Coverage The following is added to the Coverage Provision of the Physical Damage Coverage Section: Personal Effects Coverage a. We will pay up to $750 for loss" to personal effects which are: (1) Personal property owned by an "insured" and (2) In or on a covered "auto". b. Subject to Paragraph a, above, the amount to be paid for loss" to personal effects will be based on the lesser of: (1) The reasonable cost to replace; or (2) The actual cash value. c. The coverage provided in Paragraphs a. and b. above, only applies in the event of a total theft of a covered "auto". No deductible applies to this coverage. However, we will not pay for 'loss" to personal effects of any of the following: (1) Accounts, bills, currency, deeds, evidence of debt, money, notes, securities, or commercial paper or other documents of value. (2) Bullion, gold, silver, platinum, or other precious alloys or metals; furs or fur garments; jewelry, watches, precious or semi-precious stones. (3) Paintings, statuary and other works of art. (4) Contraband or property in the course of illegal transportation or trade. (5) Tapes, records, discs or other similar devices used with audio, visual or data electronic equipment. Any coverage provided by this Provision is excess over any other insurance coverage available for the same "loss". J. Tapes, Records and Discs Coverage 1. The Exclusion in Paragraph BA.a. of Section III — Physical Damage Coverage in the Business Auto Coverage Form and the Exclusion in Paragraph B.2.c. of Section IV — Physical Damage Coverage in the Motor Carrier Coverage Form does not apply. 2. The following is added to Paragraph 1.a. Comprehensive Coverage under the Coverage Provision of the Physical Damage Coverage Section: We will pay for loss" to tapes, records, discs or other similar devices used with audio, visual or data electronic equipment. We will pay only if the tapes, records, discs or other similar audio, visual or data electronic devices: (a) Are the property of an "insured"; and (b) Are in a covered "auto' at the time of "loss". The most we will pay for such 'loss" to tapes, records, discs or other similar devices is $500. The Physical Damage Coverage Deductible Provision does not apply to such 'loss". Rlele Managzmad Divislun c RE�\AewED&APPRovEo8r rrDVSAWI Risk Management Analyst Includes copyrighted material of Insurance Services Office, Inc., with its permission. K. Airbag Coverage The Exclusion in Paragraph B.3.a. of Section III — Physical Damage Coverage in the Business Auto Coverage Form and the Exclusion in Paragraph BA.a. of Section IV — Physical Damage Coverage in the Motor Carrier Coverage Form does not apply to the accidental discharge of an airbag. L. Two or More Deductibles The following is added to the Deductible Provision of the Physical Damage Coverage Section: If an accident is covered both by this policy or Coverage Form and by another policy or Coverage Form issued to you by us, the following applies for each covered "auto" on a per vehicle basis: 1. If the deductible on this policy or Coverage Form is the smaller (or smallest) deductible, it will be waived; or 2. If the deductible on this policy or Coverage Form is not the smaller (or smallest) deductible, it will be reduced by the amount of the smaller (or smallest) deductible. M. Physical Damage — Comprehensive Coverage — Deductible The following is added to the Deductible Provision of the Physical Damage Coverage Section: Regardless of the number of covered "autos" damaged or stolen, the maximum deductible that will be applied to Comprehensive Coverage for all 'loss" from any one cause is $5,000 or the deductible shown in the Declarations, whichever is greater. N. Temporary Substitute Autos — Physical Damage 1. The following is added to Section I — Covered Autos: Temporary Substitute Autos — Physical Damage If Physical Damage Coverage is provided by this Coverage Form on your owned covered "autos", the following types of vehicles are also covered "autos" for Physical Damage Coverage: Any "auto' you do not own when used with the permission of its owner as a temporary substitute for a covered "auto" you do own but is out of service because of its: 1. Breakdown; 2. Repair; 3. Servicing; 4. "Loss"; or 5. Destruction. 2. The following is added to the Paragraph A. Coverage Provision of the Physical Damage Coverage Section: Temporary Substitute Autos — Physical Damage We will pay the owner for 'loss" to the temporary substitute "auto' unless the 'loss" results from fraudulent acts or omissions on your part. If we make any payment to the owner, we will obtain the owner's rights against any other party. The deductible for the temporary substitute "auto' will be the same as the deductible for the covered "auto' it replaces. O. Amended Duties In The Event Of Accident, Claim, Suit Or Loss Paragraph a, of the Duties In The Event Of Accident, Claim, Suit Or Loss Condition is replaced by the following: a. In the event of "accident', claim, "suit' or "loss", you must give us or our authorized representative prompt notice of the "accident', claim, "suit' or 'loss". However, these duties only apply when the "accident', claim, "suit' or "loss" is known to you (if you are an individual), a partner (if you are a partnership), a member (if you are a limited liability company) or an executive officer or insurance manager (if you are a corporation). The failure of any i REm APPRav®DttietoMvw&By,. F«o a z �. VztLsn..d ®, Risk Management Analyst Includes copyrighted material of Insurance Services Office, Inc., with its permission. agent, servant or employee of the "insured" to notify us of any "accident", claim, "suit" or "loss" shall not invalidate the insurance afforded by this policy. Include, as soon as practicable: (1) How, when and where the "accident" or "loss" occurred and if a claim is made or "suit" is brought, written notice of the claim or "suit" including, but not limited to, the date and details of such claim or "suit"; (2) The "insured's" name and address; and (3) To the extent possible, the names and addresses of any injured persons and witnesses. If you report an "accident", claim, "suit" or "loss" to another insurer when you should have reported to us, your failure to report to us will not be seen as a violation of these amended duties provided you give us notice as soon as practicable after the fact of the delay becomes known to you. P. Waiver of Transfer Of Rights Of Recovery Against Others To Us The following is added to the Transfer Of Rights Of Recovery Against Others To Us Condition: This Condition does not apply to the extent required of you by a written contract, executed prior to any "accident" or "loss", provided that the "accident" or "loss" arises out of operations contemplated by such contract. This waiver only applies to the person or organization designated in the contract. Q. Employee Hired Autos — Physical Damage Paragraph b, of the Other Insurance Condition in the Business Auto Coverage Form and Paragraph f. of the Other Insurance — Primary and Excess Insurance Provisions Condition in the Motor Carrier Coverage Form are replaced by the following: For Hired Auto Physical Damage Coverage, the following are deemed to be covered "autos" you own: (1) Any covered "auto" you lease, hire, rent or borrow; and (2) Any covered "auto" hired or rented under a written contract or written agreement entered into by an "employee" or elected or appointed official with your permission while being operated within the course and scope of that "employee's" employment by you or that elected or appointed official's duties as respect their obligations to you. However, any "auto" that is leased, hired, rented or borrowed with a driver is not a covered "auto". R. Unintentional Failure to Disclose Hazards The following is added to the Concealment, Misrepresentation Or Fraud Condition: However, we will not deny coverage under this Coverage Form if you unintentionally: (1) Fail to disclose any hazards existing at the inception date of this Coverage Form; or (2) Make an error, omission, improper description of "autos" or other misstatement of information. You must notify us as soon as possible after the discovery of any hazards or any other information that was not provided to us prior to the acceptance of this policy. S. Hired Auto —World Wide Coverage Paragraph 7a.(5) of the Policy Period, Coverage Territory Condition is replaced by the following: (5) Anywhere in the world if a covered "auto" is leased, hired, rented or borrowed for a period of 60 days or less, T. Bodily Injury Redefined The definition of "bodily injury" in the Definitions Section is replaced by the following: "Bodily injury" means bodily injury, sickness or disease, sustained by a person including death or mental anguish, resulting from any of these at any time. Mental anguish means any type of mental or emotional illness or disease. RIm4 Management Division REmemm & APPRav® Br. �_4>flf.11.lfJc' Fu� PZ. (1:f,(i4"t �'. Risk Management Analyst Includes copyrighted material of Insurance services Office, Inc., with its permission. U. Expected Or Intended Injury The Expected Or Intended Injury Exclusion in Paragraph B. Exclusions under Section II — Covered Auto Liability Coverage is replaced by the following: Expected Or Intended Injury "Bodily injury" or "property damage" expected or intended from the standpoint of the "insured". This exclusion does not apply to "bodily injury" or "property damage" resulting from the use of reasonable force to protect persons or property. V. Physical Damage —Additional Temporary Transportation Expense Coverage Paragraph A.4.a. of Section III — Physical Damage Coverage is replaced by the following: 4. Coverage Extensions a. Transportation Expenses We will pay up to $50 per day to a maximum of $1,000 for temporary transportation expense incurred by you because of the total theft of a covered "auto" of the private passenger type. We will pay only for those covered "autos" for which you carry either Comprehensive or Specified Causes of Loss Coverage. We will pay for temporary transportation expenses incurred during the period beginning 48 hours after the theft and ending, regardless of the policy's expiration, when the covered "auto" is returned to use or we pay for its "loss". W. Replacement of a Private Passenger Auto with a Hybrid or Alternative Fuel Source Auto The following is added to Paragraph A. Coverage of the Physical Damage Coverage Section: In the event of a total "loss" to a covered "auto" of the private passenger type that is replaced with a hybrid "auto" or "auto" powered by an alternative fuel source of the private passenger type, we will pay an additional 10% of the cost of the replacement "auto", excluding tax, title, license, other fees and any aftermarket vehicle upgrades, up to a maximum of $2500. The covered "auto" must be replaced by a hybrid "auto" or an "auto" powered by an alternative fuel source within 60 calendar days of the payment of the "loss" and evidenced by a bill of sale or new vehicle lease agreement. To qualify as a hybrid "auto", the "auto" must be powered by a conventional gasoline engine and another source of propulsion power. The other source of propulsion power must be electric, hydrogen, propane, solar or natural gas, either compressed or liquefied. To qualify as an "auto" powered by an alternative fuel source, the "auto" must be powered by a source of propulsion power other than a conventional gasoline engine. An "auto" solely propelled by biofuel, gasoline or diesel fuel or any blend thereof is not an "auto" powered by an alternative fuel source. X. Return of Stolen Automobile The following is added to the Coverage Extension Provision of the Physical Damage Coverage Section: If a covered "auto' is stolen and recovered, we will pay the cost of transport to return the "auto" to you. We will pay only for those covered "autos" for which you carry either Comprehensive or Specified Causes of Loss Coverage. All other terms, conditions, provisions and exclusions of this policy remain the same. Risk Management Elhision REVIEWED&APPR vED av [: � WNL®llJ%L` r 4F1.Nn1 ram. V:+.+M"I ®- Risk Management Analyst Includes copyrighted material of Insurance Services Office, Inc., with its permission. WORKERS' COMPENSATION AND EMPLOYERS' LIABILITY INSURANCE POLICY WC 04 03 06 (Ed. 4-84) WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT- CALIFORNIA This endorsement changes the policy to which it is attached effective on the inception date of the policy unless a different date is indicated below. (The following "attaching clause" need be completed only when this endorsement is issued subsequent to preparation of the policy.) This endorsement, effective on 10/01/2021 at 12:01 A.M. standard time, forms a part of (DATE) Policy No. WC-3243711-03 of the issued to Leed Electric, Inc. Premium (if any) $ Endorsement No. Zurich American Insurance Company Authorized Representative We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule. (This agreement applies only to the extent that you perform work under a written contract that requires you to obtain this agreement from us.) You must maintain payroll records accurately segregating the remuneration of your employees while engaged in the work described in the Schedule. The additional premium for this endorsement shall be mium otherwise due on such remuneration. Schedule Person or Organization % of the California workers' compensation pre - Job Description ALL PERSONS AND/OR ORGANIZATIONS THAT ARE REQUIRED BY WRITTEN CONTRACT OR AGREEMENT WITH THE INSURED, EXECUTED PRIOR TO THE ACCIDENT OR LOSS, THAT WAIVER OF SUBROGATION BE PROVIDED UNDER THIS POLICY FOR WORK PERFORMED BY YOU FOR THAT PERSON AND/OR ORGANIZATION. WC 252 (4-84) WC 04 03 06 (Ed. 4-84) Rick Management Dbieion I/`�Rentweo 6 APPRav®Br. �� Risk Management Analyst Schedule of Underlying Insurance ZURICH Policy No. Eff. Date of Pol. Exp. Date of Poi. Eff. Date of End. Producer Add'I Prem. Return Prem. AUC 3243712-03 10/01/2021 10/01/2022 10/01/2021 75272000 __________ Named Insured and Mailing Address: LEED ELECTRIC, INC. 13138 ARCTIC CIRCLE SANTA FE SPRINGS, CA 90670 Producer: AON RISK INSURANCE SERVICES WEST, INC. 707 WILSHIRE BLVD STE 2600 LOS ANGELES, CA 90017-3533 Company, Policy No. and Term Coverage Applicable Limits A. Company: ZURICH AMERICAN Commercial General $1,000,000 Premises - Each INSURANCE COMPANY Liability Occurrence Policy No: GLO 3230758-03 Term: 10/01/2021 to 10/0112022 Commercial General Liability Including Employee Benefits $1,000,000 Products/ Completed Ops - Each Occurrence $2,000,000 Products / Completed Operations Aggregate $2,000,000 General Aggregate $1,000,000 Employee Benefits - Each Claim $2,000,000 Employee Benefits - General Aggregate Company, Policy No. and Term Coverage Applicable Limits B. Company: ZURICH AMERICAN Commercial Auto Liability $1,000,000 Combined Single INSURANCE COMPANY Limit Policy No: BAP 3230759-03 Automobile Liability Term: 10/01/2021 to 10/01/2022 Company, Policy No. and Term Coverage Applicable Limits C. Company: ZURICH AMERICAN Employers Liability $1,000,000 Bodily Injury By INSURANCE COMPANY Accident - Each Accident Policy No: WC 3243711-03 Employers Liability $1,000,000 Bodily Injury By Disease - Each Employee Risk Reii wm> pPovm ar. Ruk Management Analyst Term: 10/01/2021 to 10/01/2022 $1,000,000 Bodily Injury By Disease - Policy Limit R7e1 Mnnagenient oiwmn RE%AEw &Arwtov®Ely: �i Ruk Management Analyst NOTICE OF COMPLIANCE Contractor Leed Electric, Inc. Name: Project A-2022-025-02 Number: Project A-2022-025-02 Name: The Certificate of Insurance (COI) submitted indicates that the coverages are in compliance with the insurance requirements. No further action is required at this time. The compliant coverage(s) are: POLICY EXPIRATION TYPE OF INSURANCE COI DATE FILE NAME NUMBER DATE LEI AUTOMOBILE LIABILITY 72UEACI2219 10/01/2023 10/03/2022 COI _2023_CITY OF SANTA ANA.pdf LEI CONTRACTORS PROFESSIONAL LIABILITY / COI_2023_CITY 36CPIAE8158 10/01/2023 10/03/2022 , POLLU OFSANTA ANA.pdf LEI COI GENERAL LIABILITY 72UEACI2220 10/01/2023 10/03/2022 _2023_CITY OF SANTA ANA.pdf LEI WORKERS COMPENSATION AND COI 72WEAAT3GK7 10/01/2023 10/03/2022 _2023_CITY EMPLOYERS' LIABILITY OF SANTA ANA.pdf Thank you, City of Santa Ana Risk Management Division in partnership with CTrax Plus Services Team NOTICE OF COMPLIANCE CITY "A',1CC. I1111RINT I'III I III°i II11AG➢E AND INCLUDE CE I 11111 AGR E➢E k1➢EN I TO 1111I E CLERIC CSC 1111I E COUNCIL L Contractor Leed Electric, Inc. Name: Project A-2022-025-02 Number: Project Agreement To Provide On -Call Electrical Repair And Rehabilitation Services Name: The Certificate of Insurance (COI) submitted indicates that the coverages are in compliance with the insurance requirements. No further action is required at this time. The compliant coverage(s) are: EXPIRATION TYPE OF INSURANCE POLICY NUMBER COI DATE FILE NAME DATE AUTOMOBILE LIABILITY BAP422779500 10/01/2024 09/27/2023 Leed Electric COI.pdf 2023-2024 Certificate of Insurance - City GENERAL LIABILITY A0230199003 10/01/2024 10/24/2023 of Santa Ana - Risk Management Division.pdf 2023-2024 Certificate of Insurance - City POLL/PROF LIAB. PECO064286 10/01/2024 10/24/2023 of Santa Ana - Risk Management Division.pdf WORKERS COMPENSATION AND EMPLOYERS' WC564657300 10/01/2024 09/27/2023 Leed Electric LIABILITY COI.pdf Thank you, City of Santa Ana Risk Management Division in partnership with CTrax Plus Services Team 10/25/2023 11:08 AM LEEDELE-01 1LOPEZ ,acoRO CERTIFICATE OF LIABILITY INSURANCE FDAATE(MM/DD/YYYY) 9/26/2024 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT Jessica Lopez NAME: PHONE FAX (A/C, No, Ext): (949) 287-5677 (A/C, No): (949) 335-0621 Commercial The Brokerage The Brokerage, an Alera Group Company 20261 SW Acacia St, Suite 200 a DDRIESS: jlopez@thebrokerageins.com Newport Beach, CA 92660 INSURER S AFFORDING COVERAGE NAIC # INSURERA: Middlesex Insurance Company 23434 INSURED INSURERB:ZURICH AMERICAN INSURANCE COMPANY 16535 INSURER C : TRAVELERS PROPERTY CASUALTY COMPANY OF AMERICA 25674 Leed Electric, Inc. INSURER D: Indian Harbor Insurance Company 36940 13138 Arctic Circle Santa Fe Springs, CA 90670 INSURER E INSURER F : COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR LTR TYPE OF INSURANCE ADDL INSD SUBR WVD POLICY NUMBER POLICY EFF MWDD/YYYY POLICY EXP YY MM/DD/YY LIMITS A X COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ 1,000,000 CLAIMS -MADE X OCCUR X X A0230199003 10/1/2024 10/1/2025 DAMAGE TO RENTED PREMISES Ea occurrence 500,000 $ MED EXP (Any oneperson) $ 10,000 PERSONAL & ADV INJURY $ 1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ 3,000,000 POLICY X JECT El LOC PRODUCTS - COMP/OPAGG $ 2,000,000 $ OTHER: B AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT Ea accident 1,000,000 $ X BODILY INJURY Perperson) $ ANY AUTO X X BAP 4227795 - 01 10/1/2024 10/1/2025 OWNED SCHEDULED AUTOS ONLY AUTOS BODILY INJURY Per accident $ PROPERTY DAMAGE Per accident $ HIRED NON -OWNED AUTOS ONLY AUTOS ONLY C X UMBRELLA LIAB X OCCUR EACH OCCURRENCE $ 2,000,000 EXCESS LIAB CLAIMS -MADE X X CUP-3XO79407-24-NF 10/1/2024 10/1/2025 AGGREGATE $ 2,000,000 DED X RETENTION $ 0 $ B WORKERS COMPENSATION AND EMPLOYERS' LIABILITY ANY PROPRIETOR/PARTNER/EXECUTIVE X WC 5646573 -01 10/1/2024 10/1/2025 X PER OTH- STATUTE ER E.L. EACH ACCIDENT 1,000,000 $ OFFICER/MEMBER EXCLUDED? ❑ (Mandatory in NH) N/A E.L. DISEASE- EA EMPLOYEE $ 1,000,000 If yes, describe under DESCRIPTION OF OPERATIONS below E.L. DISEASE - POLICY LIMIT 1,000,000 $ D Poll/Prof Liab. PECO064286 10/1/2024 10/1/2025 $2Mill Occ/Agg: 3,000,000 DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) RE: Agreement: A-2022-025-02; Agreement To Provide On -Call Electrical Repair And Rehabilitation Services. glaiwv/auaiwv/wcwv/xsaiwv City of Santa Ana, its officers, employees, volunteers, agents and representatives and any other entity which contractor is required are included as Additional Insureds as respects General Liability, Auto Liability, and Umbrella Liability per attached endorsements. This Insurance shall apply as Primary and Non -Contributory per attached endorsement. Waiver of Subrogation for Workers' Compensation, General Liability, Auto Liability, and Umbrella Liability: See Attached Endorsements. "Excess Liability follows form over the General Liability, Auto Liability, and Employers Liability. APPROVED City of Santa Ana - Risk Management Division 20 Civic Center Plaza, 4th Floor Santa Ana, CA 92701 By Cynthia Mora at 9.03 am, Jan 08, 202b SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE ACORD 25 (2016/03) © 1988-2015 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD AFRO AGENCY CUSTOMER ID: LEEDELE-01 LOC #: 1 ADDITIONAL REMARKS SCHEDULE AGENCY NAMED INSURED Leed Commercial The Brokerage 1313a 1313 Electric, Inc. 8 Arctic Circle POLICY NUMBER Santa Fe Springs, CA 90670 SEE PAGE 1 CARRIER NAIC CODE SEE PAGE 1 SEE P 1 EFFECTIVE DATE: SEE PAGE 1 LDDITIONAL REMARKS THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM, FORM NUMBER: ACORD 25 FORM TITLE: Certificate of Liability Insurance JLOPEZ Page 1 of 1 Cancellation: *Should this policy be cancelled before the expiration date, The Brokerage, an Alera Group Company will mail 30 (thirty) days written notice to those Certificate Holders which require such action per contract or agreement.* *Except 10 Days Notice of Cancellation for Non -Payment of Premium. ACORD 101 (2008/01) © 2008 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD POLICY NUMBER: A0230199003 COMMERCIAL GENERAL LIABILITY CG20101219 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - SCHEDULED PERSON OR ORGANIZATION This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name Of Additional Insured Person(s) Or Organization(s) Location(s) Of Covered Operations Any person or organization you are required to add as All locations per written contract, agreement, or permit. an additional insured under a written contract or agreement in effect prior to any accident, injury, loss Description: All jobs performed that have a written or damage. contract, agreement, or permit. Information required to complete this Schedule, if not shown above, will be shown in the Declarations. A. Section II - Who Is An Insured is amended to include as an additional insured the person(s) or organization(s) shown in the Schedule, but only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by: 1. Your acts or omissions; or 2. The acts or omissions of those acting on your behalf; in the performance of your ongoing operations for the additional insured(s) at the location(s) designated above. However: 1. The insurance afforded to such additional insured only applies to the extent permitted by law; and 2. If coverage provided to the additional insured is required by a contract or agreement, the insurance afforded to such additional insured will not be broader than that which you are required by the contract or agreement to provide for such additional insured. B. With respect to the insurance afforded to these additional insureds, the following additional exclusions apply: This insurance does not apply to "bodily injury" or "property damage" occurring after: 1. All work, including materials, parts or equipment furnished in connection with such work, on the project (other than service, maintenance or repairs) to be performed by or on behalf of the additional insured(s) at the location of the covered operations has been completed; or 2. That portion of "your work" out of which the injury or damage arises has been put to its intended use by any person or organization other than another contractor or subcontractor engaged in performing operations for a principal as a part of the same project. CG 20 10 12 19 © Insurance Services Office, Inc., 2018 Middlesex Insurance Company 1 00001 0000000000 24263 0 N a446f692-f058488d-b503-ecae566ee9ec Page 1 of 2 C. With respect to the insurance afforded to these additional insureds, the following is added to Section III - Limits Of Insurance: If coverage provided to the additional insured is required by a contract or agreement, the most we will pay on behalf of the additional insured is the amount of insurance: 1. Required by the contract or agreement; or 2. Available under the applicable limits of insurance; whichever is less. This endorsement shall not increase the applicable limits of insurance. Page 2 of 2 Middlesex Insurance Company © Insurance Services Office, Inc., 2018 C e*11111111HEK POLICY NUMBER: A0230199003 COMMERCIAL GENERAL LIABILITY CG20371219 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - COMPLETED OPERATIONS This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART SCHEDULE Name Of Additional Insured Person(s) Or Organization(s) Location And Description Of Completed Operations Any person or organization you are required to add as All locations and jobs performed that have a written an additional insured under a written contract or contract, agreement, or permit. agreement in effect prior to any accident, injury, loss or damage. Information required to complete this Schedule, if not shown above, will be shown in the Declarations. A. Section II - Who Is An Insured is amended to include as an additional insured the person(s) or organization(s) shown in the Schedule, but only with respect to liability for "bodily injury" or "property damage" caused, in whole or in part, by "your work" at the location designated and described in the Schedule of this endorsement performed for that additional insured and included in the "products -completed operations hazard". However: 1. The insurance afforded to such additional insured only applies to the extent permitted by law; and 2. If coverage provided to the additional insured is required by a contract or agreement, the insurance afforded to such additional insured will not be broader than that which you are required by the contract or agreement to provide for such additional insured. B. With respect to the insurance afforded to these additional insureds, the following is added to Section III - Limits Of Insurance: If coverage provided to the additional insured is required by a contract or agreement, the most we will pay on behalf of the additional insured is the amount of insurance: 1. Required by the contract or agreement; or 2. Available under the applicable limits of insurance; whichever is less. This endorsement shall not increase the applicable limits of insurance. CG 20 37 12 19 © Insurance Services Office, Inc., 2018 Middlesex Insurance Company 1 00001 0000000000 24263 0 N 47fa9bb2-e8db-45fa-a04f-522cebOde319 Page 1 of 1 POLICY NUMBER: A0230199003 COMMERCIAL GENERAL LIABILITY CG24041219 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US (WAIVER OF SUBROGATION) This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART ELECTRONIC DATA LIABILITY COVERAGE PART LIQUOR LIABILITY COVERAGE PART POLLUTION LIABILITY COVERAGE PART DESIGNATED SITES POLLUTION LIABILITY LIMITED COVERAGE PART DESIGNATED SITES PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART RAILROAD PROTECTIVE LIABILITY COVERAGE PART UNDERGROUND STORAGE TANK POLICY DESIGNATED TANKS SCHEDULE Name Of Person(s) Or Organization(s): WHEN REQUIRED BY WRITTEN CONTRACT AND WHERE PERMITTED BY LAW Information required to complete this Schedule, if not shown above, will be shown in the Declarations. The following is added to Paragraph 8. Transfer Of Rights Of Recovery Against Others To Us of Section IV — Conditions: We waive any right of recovery against the person(s) or organization(s) shown in the Schedule above because of payments we make under this Coverage Part. Such waiver by us applies only to the extent that the insured has waived its right of recovery against such person(s) or organization(s) prior to loss. This endorsement applies only to the person(s) or organization(s) shown in the Schedule above. CG 24 04 12 19 © Insurance Services Office, Inc., 2018 Page 1 of 1 INSURED COPY Coverage Extension Endorsement ZURICH Policy No. Eff. Date of Pol. Exp. Date of Pol. Eff. Date of End. Producer No. Add'I. Prem Return Prem. BAP 4227795-01 1 10/01 /2024 10/01 /2025 1 10/01 /2024 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. This endorsement modifies insurance provided under the: Business Auto Coverage Form Motor Carrier Coverage Form A. Amended Who Is An Insured 1. The following is added to the Who Is An Insured Provision in Section II — Covered Autos Liability Coverage: The following are also "insureds": a. Any "employee" of yours is an "insured" while using a covered "auto" you don't own, hire or borrow for acts performed within the scope of employment by you. Any "employee" of yours is also an "insured" while operating an "auto" hired or rented under a contract or agreement in an "employee's" name, with your permission, while performing duties related to the conduct of your business. b. Anyone volunteering services to you is an "insured" while using a covered "auto" you don't own, hire or borrow to transport your clients or other persons in activities necessary to your business. c. Anyone else who furnishes an "auto" referenced in Paragraphs A.1.a. and A.1.b. in this endorsement. d. Where and to the extent permitted by law, any person(s) or organization(s) where required by written contract or written agreement with you executed prior to any "accident", including those person(s) or organization(s) directing your work pursuant to such written contract or written agreement with you, provided the "accident" arises out of operations governed by such contract or agreement and only up to the limits required in the written contract or written agreement, or the Limits of Insurance shown in the Declarations, whichever is less. 2. The following is added to the Other Insurance Condition in the Business Auto Coverage Form and the Other Insurance — Primary and Excess Insurance Provisions Condition in the Motor Carrier Coverage Form: Coverage for any person(s) or organization(s), where required by written contract or written agreement with you executed prior to any "accident", will apply on a primary and non-contributory basis and any insurance maintained by the additional "insured" will apply on an excess basis. However, in no event will this coverage extend beyond the terms and conditions of the Coverage Form. B. Amendment — Supplementary Payments Paragraphs a.(2) and a.(4) of the Coverage Extensions Provision in Section II — Covered Autos Liability Coverage are replaced by the following: (2) Up to $5,000 for the cost of bail bonds (including bonds for related traffic law violations) required because of an "accident" we cover. We do not have to furnish these bonds. (4) All reasonable expenses incurred by the "insured" at our request, including actual loss of earnings up to $500 a day because of time off from work. U-CA-424-F CW (04/14) Page 1 of 6 Includes copyrighted material of Insurance Services Office, Inc., with its permission. C. Fellow Employee Coverage The Fellow Employee Exclusion contained in Section II — Covered Autos Liability Coverage does not apply. D. Driver Safety Program Liability and Physical Damage Coverage 1. The following is added to the Racing Exclusion in Section II — Covered Autos Liability Coverage: This exclusion does not apply to covered "autos" participating in a driver safety program event, such as, but not limited to, auto or truck rodeos and other auto or truck agility demonstrations. 2. The following is added to Paragraph 2. in the Exclusions of Section III — Physical Damage Coverage of the Business Auto Coverage Form and Paragraph 2.b. in the Exclusions of Section IV — Physical Damage Coverage of the Motor Carrier Coverage Form: This exclusion does not apply to covered "autos" participating in a driver safety program event, such as, but not limited to, auto or truck rodeos and other auto or truck agility demonstrations. E. Lease or Loan Gap Coverage The following is added to the Coverage Provision of the Physical Damage Coverage Section: Lease Or Loan Gap Coverage In the event of a total "loss" to a covered "auto", we will pay any unpaid amount due on the lease or loan for a covered "auto", less: a. Any amount paid under the Physical Damage Coverage Section of the Coverage Form; and b. Any: (1) Overdue lease or loan payments at the time of the "loss"; (2) Financial penalties imposed under a lease for excessive use, abnormal wear and tear or high mileage; (3) Security deposits not returned by the lessor; (4) Costs for extended warranties, credit life insurance, health, accident or disability insurance purchased with the loan or lease; and (5) Carry-over balances from previous leases or loans. F. Towing and Labor Paragraph A.2. of the Physical Damage Coverage Section is replaced by the following: We will pay up to $75 for towing and labor costs incurred each time a covered "auto" of the private passenger type is disabled. However, the labor must be performed at the place of disablement. G. Extended Glass Coverage The following is added to Paragraph A.3.a. of the Physical Damage Coverage Section: If glass must be replaced, the deductible shown in the Declarations will apply. However, if glass can be repaired and is actually repaired rather than replaced, the deductible will be waived. You have the option of having the glass repaired rather than replaced. H. Hired Auto Physical Damage — Increased Loss of Use Expenses The Coverage Extension for Loss Of Use Expenses in the Physical Damage Coverage Section is replaced by the following: Loss Of Use Expenses For Hired Auto Physical Damage, we will pay expenses for which an "insured" becomes legally responsible to pay for loss of use of a vehicle rented or hired without a driver under a written rental contract or written rental agreement. We will pay for loss of use expenses if caused by: U-CA-424-F CW (04/14) Page 2 of 6 Includes copyrighted material of Insurance Services Office, Inc., with its permission. (1) Other than collision only if the Declarations indicate that Comprehensive Coverage is provided for any covered "auto"; (2) Specified Causes Of Loss only if the Declarations indicate that Specified Causes Of Loss Coverage is provided for any covered "auto"; or (3) Collision only if the Declarations indicate that Collision Coverage is provided for any covered "auto". However, the most we will pay for any expenses for loss of use is $100 per day, to a maximum of $3000. I. Personal Effects Coverage The following is added to the Coverage Provision of the Physical Damage Coverage Section: Personal Effects Coverage a. We will pay up to $750 for "loss" to personal effects which are: (1) Personal property owned by an "insured"; and (2) In or on a covered "auto". b. Subject to Paragraph a. above, the amount to be paid for "loss" to personal effects will be based on the lesser of: (1) The reasonable cost to replace; or (2) The actual cash value. c. The coverage provided in Paragraphs a. and b. above, only applies in the event of a total theft of a covered "auto". No deductible applies to this coverage. However, we will not pay for 'loss" to personal effects of any of the following: (1) Accounts, bills, currency, deeds, evidence of debt, money, notes, securities, or commercial paper or other documents of value. (2) Bullion, gold, silver, platinum, or other precious alloys or metals; furs or fur garments; jewelry, watches, precious or semi-precious stones. (3) Paintings, statuary and other works of art. (4) Contraband or property in the course of illegal transportation or trade. (5) Tapes, records, discs or other similar devices used with audio, visual or data electronic equipment. Any coverage provided by this Provision is excess over any other insurance coverage available for the same 'loss". J. Tapes, Records and Discs Coverage 1. The Exclusion in Paragraph 13.4.a. of Section III — Physical Damage Coverage in the Business Auto Coverage Form and the Exclusion in Paragraph B.2.c. of Section IV — Physical Damage Coverage in the Motor Carrier Coverage Form does not apply. 2. The following is added to Paragraph 1.a. Comprehensive Coverage under the Coverage Provision of the Physical Damage Coverage Section: We will pay for 'loss" to tapes, records, discs or other similar devices used with audio, visual or data electronic equipment. We will pay only if the tapes, records, discs or other similar audio, visual or data electronic devices: (a) Are the property of an "insured"; and (b) Are in a covered "auto" at the time of "loss". The most we will pay for such 'loss" to tapes, records, discs or other similar devices is $500. The Physical Damage Coverage Deductible Provision does not apply to such "loss". U-CA-424-F CW (04/14) Page 3 of 6 Includes copyrighted material of Insurance Services Office, Inc., with its permission. K. Airbag Coverage The Exclusion in Paragraph B.3.a. of Section III — Physical Damage Coverage in the Business Auto Coverage Form and the Exclusion in Paragraph B.4.a. of Section IV — Physical Damage Coverage in the Motor Carrier Coverage Form does not apply to the accidental discharge of an airbag. L. Two or More Deductibles The following is added to the Deductible Provision of the Physical Damage Coverage Section: If an accident is covered both by this policy or Coverage Form and by another policy or Coverage Form issued to you by us, the following applies for each covered "auto" on a per vehicle basis: 1. If the deductible on this policy or Coverage Form is the smaller (or smallest) deductible, it will be waived; or 2. If the deductible on this policy or Coverage Form is not the smaller (or smallest) deductible, it will be reduced by the amount of the smaller (or smallest) deductible. M. Physical Damage — Comprehensive Coverage — Deductible The following is added to the Deductible Provision of the Physical Damage Coverage Section: Regardless of the number of covered "autos" damaged or stolen, the maximum deductible that will be applied to Comprehensive Coverage for all "loss" from any one cause is $5,000 or the deductible shown in the Declarations, whichever is greater. N. Temporary Substitute Autos — Physical Damage 1. The following is added to Section I — Covered Autos: Temporary Substitute Autos — Physical Damage If Physical Damage Coverage is provided by this Coverage Form on your owned covered "autos", the following types of vehicles are also covered "autos" for Physical Damage Coverage: Any "auto" you do not own when used with the permission of its owner as a temporary substitute for a covered "auto" you do own but is out of service because of its: 1. Breakdown; 2. Repair; 3. Servicing; 4. "Loss"; or 5. Destruction. 2. The following is added to the Paragraph A. Coverage Provision of the Physical Damage Coverage Section: Temporary Substitute Autos — Physical Damage We will pay the owner for "loss" to the temporary substitute "auto" unless the "loss" results from fraudulent acts or omissions on your part. If we make any payment to the owner, we will obtain the owner's rights against any other party. The deductible for the temporary substitute "auto" will be the same as the deductible for the covered "auto" it replaces. O. Amended Duties In The Event Of Accident, Claim, Suit Or Loss Paragraph a. of the Duties In The Event Of Accident, Claim, Suit Or Loss Condition is replaced by the following: a. In the event of "accident", claim, "suit" or "loss", you must give us or our authorized representative prompt notice of the "accident", claim, "suit" or "loss". However, these duties only apply when the "accident", claim, "suit" or "loss" is known to you (if you are an individual), a partner (if you are a partnership), a member (if you are a limited liability company) or an executive officer or insurance manager (if you are a corporation). The failure of any U-CA-424-F CW (04/14) Page 4 of 6 Includes copyrighted material of Insurance Services Office, Inc., with its permission. agent, servant or employee of the "insured" to notify us of any "accident", claim, "suit" or "loss" shall not invalidate the insurance afforded by this policy. Include, as soon as practicable: (1) How, when and where the "accident" or "loss" occurred and if a claim is made or "suit" is brought, written notice of the claim or "suit" including, but not limited to, the date and details of such claim or "suit"; (2) The "insured's" name and address; and (3) To the extent possible, the names and addresses of any injured persons and witnesses. If you report an "accident", claim, "suit" or "loss" to another insurer when you should have reported to us, your failure to report to us will not be seen as a violation of these amended duties provided you give us notice as soon as practicable after the fact of the delay becomes known to you. P. Waiver of Transfer Of Rights Of Recovery Against Others To Us The following is added to the Transfer Of Rights Of Recovery Against Others To Us Condition: This Condition does not apply to the extent required of you by a written contract, executed prior to any "accident" or "loss", provided that the "accident" or "loss" arises out of operations contemplated by such contract. This waiver only applies to the person or organization designated in the contract. Q. Employee Hired Autos — Physical Damage Paragraph b. of the Other Insurance Condition in the Business Auto Coverage Form and Paragraph f. of the Other Insurance — Primary and Excess Insurance Provisions Condition in the Motor Carrier Coverage Form are replaced by the following: For Hired Auto Physical Damage Coverage, the following are deemed to be covered "autos" you own: (1) Any covered "auto" you lease, hire, rent or borrow; and (2) Any covered "auto" hired or rented under a written contract or written agreement entered into by an "employee" or elected or appointed official with your permission while being operated within the course and scope of that "employee's" employment by you or that elected or appointed official's duties as respect their obligations to you. However, any "auto" that is leased, hired, rented or borrowed with a driver is not a covered "auto". R. Unintentional Failure to Disclose Hazards The following is added to the Concealment, Misrepresentation Or Fraud Condition: However, we will not deny coverage under this Coverage Form if you unintentionally: (1) Fail to disclose any hazards existing at the inception date of this Coverage Form; or (2) Make an error, omission, improper description of "autos" or other misstatement of information. You must notify us as soon as possible after the discovery of any hazards or any other information that was not provided to us prior to the acceptance of this policy. S. Hired Auto — World Wide Coverage Paragraph 7a.(5) of the Policy Period, Coverage Territory Condition is replaced by the following: (5) Anywhere in the world if a covered "auto" is leased, hired, rented or borrowed for a period of 60 days or less, T. Bodily Injury Redefined The definition of "bodily injury" in the Definitions Section is replaced by the following: "Bodily injury" means bodily injury, sickness or disease, sustained by a person including death or mental anguish, resulting from any of these at any time. Mental anguish means any type of mental or emotional illness or disease. U-CA-424-F CW (04/14) Page 5 of 6 Includes copyrighted material of Insurance Services Office, Inc., with its permission. U. Expected Or Intended Injury The Expected Or Intended Injury Exclusion in Paragraph B. Exclusions under Section II — Covered Auto Liability Coverage is replaced by the following: Expected Or Intended Injury "Bodily injury" or "property damage" expected or intended from the standpoint of the "insured". This exclusion does not apply to "bodily injury" or "property damage" resulting from the use of reasonable force to protect persons or property. V. Physical Damage — Additional Temporary Transportation Expense Coverage Paragraph A.4.a. of Section III — Physical Damage Coverage is replaced by the following: 4. Coverage Extensions a. Transportation Expenses We will pay up to $50 per day to a maximum of $1,000 for temporary transportation expense incurred by you because of the total theft of a covered "auto" of the private passenger type. We will pay only for those covered "autos" for which you carry either Comprehensive or Specified Causes of Loss Coverage. We will pay for temporary transportation expenses incurred during the period beginning 48 hours after the theft and ending, regardless of the policy's expiration, when the covered "auto" is returned to use or we pay for its "loss". W. Replacement of a Private Passenger Auto with a Hybrid or Alternative Fuel Source Auto The following is added to Paragraph A. Coverage of the Physical Damage Coverage Section: In the event of a total "loss" to a covered "auto" of the private passenger type that is replaced with a hybrid "auto" or "auto" powered by an alternative fuel source of the private passenger type, we will pay an additional 10% of the cost of the replacement "auto", excluding tax, title, license, other fees and any aftermarket vehicle upgrades, up to a maximum of $2500. The covered "auto" must be replaced by a hybrid "auto" or an "auto" powered by an alternative fuel source within 60 calendar days of the payment of the "loss" and evidenced by a bill of sale or new vehicle lease agreement. To qualify as a hybrid "auto", the "auto" must be powered by a conventional gasoline engine and another source of propulsion power. The other source of propulsion power must be electric, hydrogen, propane, solar or natural gas, either compressed or liquefied. To qualify as an "auto" powered by an alternative fuel source, the "auto" must be powered by a source of propulsion power other than a conventional gasoline engine. An "auto" solely propelled by biofuel, gasoline or diesel fuel or any blend thereof is not an "auto" powered by an alternative fuel source. X. Return of Stolen Automobile The following is added to the Coverage Extension Provision of the Physical Damage Coverage Section: If a covered "auto" is stolen and recovered, we will pay the cost of transport to return the "auto" to you. We will pay only for those covered "autos" for which you carry either Comprehensive or Specified Causes of Loss Coverage. All other terms, conditions, provisions and exclusions of this policy remain the same. U-CA-424-F CW (04/14) Page 6 of 6 Includes copyrighted material of Insurance Services Office, Inc., with its permission. WORKERS' COMPENSATION AND EMPLOYERS' LIABILITY INSURANCE POLICY WC 0❑03 0❑1111d. ❑1111❑❑ WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT- CALIFORNIA This endorsement changes the policy to which it is attached effective on the inception date of the policy unless a different date is indicated below. the following -attaching clause -need be completed only when this endorsement is issued subsequent to preparation of the policy.- This endorsement, effective on 10/01/2024 at 12:01 A.M. standard time, forms a part of DAT-- Policy ❑o. WC 5646573 - 01 of the issued to Leed Electric, Inc. Premium if any ❑ndorsement ❑o. Zurich American Insurance Company CAME] OF I OS❑RA❑C❑ COMPA-Y- Authorized Representative We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule. :This agreement applies only to the event that you perform wor❑under a written contract that requires you to obtain this agreement from us. — You must maintain payroll records accurately segregating the remuneration of your employees while engaged in the wor❑described in the Schedule. The additional premium for this endorsement shall be ❑ of the California worEOrs❑compensation pre[] mium otherwise due on such remuneration. Schedule Person or Organization ALL P❑RSO❑S A❑DOOR ORGA❑IZATIO❑S THAT AR❑ R❑Q❑IR❑D BY WRITT❑❑ CO❑TRACT OR AGR❑❑M❑❑T WITH TH❑ 111S❑R❑D, ❑❑❑C❑T❑D PRIOR TO TH❑ ACCID❑❑T OR LOSS, THAT WAIV'_1R OF S❑BROGATIO❑ B❑ PROVID❑D ❑❑D❑R THIS POLICY FOR WORD P❑RFORM❑D BY YO❑ FOR THAT P❑RSO❑ A❑DOOR ORGA❑IZATIO❑ Job Description ALL CA OP❑RATIO❑S WC 2E2 1111=o WC 0❑ 03 0❑ mod. 0=0 Page 1 of 1 One Tower Sauare, Hartford, Connecticut 06183 POLICY DECLARATIONS EXCESS FOLLOW -FORM AND UMBRELLA POLICY NO.: CUP-3X079407-24-NF LIABILITY INSURANCE POLICY ISSUE DATE: 09/25/2024 INSURING COMPANY: TRAVELERS PROPERTY CASUALTY COMPANY OF AMERICA 1. NAMED INSURED AND MAILING ADDRESS: LEED ELECTRIC, INC. 13138 ARCTIC CIRCLE SANTA FE SPRINGS CA 90670 2. POLICY PERIOD: From 10/01/2024 to 10/01/2025 12:01 A.M. Standard Time at your mailing address. 3. LIMITS OF INSURANCE: COVERAGES LIMITS OF LIABILITY AGGREGATE LIMITS OF LIABILITY $15, 000, 000 General Aggregate EXCESS FOLLOW -FORM AND UMBRELLA LIABILITY CRISIS MANAGEMENT SERVICE EXPENSES 4. SELF -INSURED RETENTION: 5. PREMIUM: $ 6. TAXES AND SURCHARGES: $15, 000, 000 Products -Completed Operations Aggregate $15, 000, 000 Occurrence Limit $150, 000 all Crisis Management Events $10, 000 any one occurrence or event 7. On the effective date shown in Item 2., the Excess Follow -Form And Umbrella Liability Insurance Policy numbered above includes this Declarations Page and any forms and endorsements shown on the Listing Of Forms, Endorsements And Schedule Numbers. 8. If the Schedule Of Underlying Insurance includes any coverage provided on a claims -made basis, then the following disclaimer applies. COVERAGE WILL APPLY ON A CLAIMS -MADE BASIS WHEN FOLLOWING CLAIMS -MADE UNDERLYING INSURANCE. 9. If the Schedule Of Underlying Insurance includes any coverage which includes defense expenses within the limits of liability, then the following disclaimer applies: DEFENSE EXPENSES ARE PAYABLE WITHIN, AND ARE NOT IN ADDITION TO, THE LIMITS OF INSURANCE WITH RESPECT TO SOME OR ALL OF THE COVERAGES PROVIDED. NAME AND ADDRESS OF AGENT OR BROKER: ALERA-ORION RISK MGMT - DKL94 20261 SW ACACIA ST STE 200 NEWPORT BEACH CA 92660 OFFICE: SP-LOS ANGELES COUNTERSIGNED BY: Authorized Representative DATE: EU 00 02 09 20 © 2019 The Travelers Indemnity Company. All rights reserved. Page 1 of 1 POLICY NUMBER: CUP-3X079407-24-NF UMBRELLA ISSUE DATE: 09/25/2024 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. SCHEDULE OF UNDERLYING INSURANCE This endorsement modifies insurance provided under the following: EXCESS FOLLOW -FORM AND UMBRELLA LIABILITY INSURANCE Employers Liability Carrier ZURICH AMERICAN INSURANCE COMPANY Policy Number WC 5646573 - 01 Policy Period From: 10/01/2024 to: 10/01/2025 *UNLIMITED IN THE STATE OF NEW YORK FOR SUBJECT EMPLOYEES Automobile Liability Carrier ZURICH AMERICAN INSURANCE COMPANY Policy Number BAP 4227795 - 01 Policy Period From: 10/01/2024 to: 10/01/2025 Commercial General Liability Carrier MIDDLESEX INSURANCE COMPANY Policy Number A0230199003 Policy Period From: 10/01/2024 to: 10/01/2025 Limits Of Liability Bodily Injury By Accident $1,000,000* Each Accident Bodily Injury By Disease $1,000,000* Policy Limit Bodily Injury By Disease $1,000,000* Each Employee Limits Of Liability Bodily Injury And Property $1,000,000 Damage Combined Single Limit Limits Of Liability General Aggregate Products -Completed Operations Aggregate Personal and Advertising Injury Each Occurrence $3,000,000 $2,000,000 $1,000,000 $1,000,000 PRODUCER:ALERA-ORION RISK MGMT OFFICE:SP-LOS ANGELES 08L EU 00 03 08 18 © 2018 The Travelers Indemnity Company. All rights reserved. Page 1 of 1 LEEDELE-01 JLOPEZ ,d►coRo CERTIFICATE OF LIABILITY INSURANCE DATE(MM/DD/YYYY) 9/29/2025 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT Jessica Lopez NAME: Commercial The Brokerage PHONE FAX The Brokerage,an Alera Group Company (A/C,No,Ext):(949)287-5677 (A/C,No):(949) 335-0621 18575 Jamboree Rd,Suite 500 a DDRIESS:llopez@thebrokerageins.com Irvine,CA 92612 INSURERS AFFORDING COVERAGE NAIC# INSURERA:Middlesex Insurance Company 23434 INSURED INSURERB:ZURICH AMERICAN INSURANCE COMPANY 16535 Leed Electric,Inc. INSURER C:TRAVELERS PROPERTY CASUALTY COMPANY OF AMERICA 25674 13138 Arctic Circle INSURER D:Indian Harbor Insurance Company 36940 Santa Fe Springs,CA 90670 INSURER E INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDL SUBR POLICY NUMBER POLICY EFF POLICY EXP LIMITS LTR INSD WVD MM/DD/YYYY MM/DD/YYYY A X COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ 1,000,000 CLAIMS-MADE X OCCUR A0230199003 10/1/2025 10/1/2026 DAMAGE TO RENTED 500,000 X X PREMISES Ea occurrence $ MED EXP(Any oneperson) $ 10,000 PERSONAL&ADV INJURY $ 1,000,000 GENT AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ 3,000,000 POLICY X 71 PEA LOC PRODUCTS-COMP/OP AGG $ 2,000,000 OTHER: $ B AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT 1,000,000 Ea accident $ X ANY AUTO X X BAP 4227795-02 10/1/2025 10/1/2026 BODILY INJURY Perperson) $ OWNED SCHEDULED AUTOS ONLY AUTOS BODILY INJURY Per accident $ HIRED NON-OWNED PROPERTY DAMAGE AUTOS ONLY AUTOS ONLY Per accident) ccident $ C X UMBRELLA LIAB X OCCUR EACH OCCURRENCE $ 2,000,000 EXCESS LAB CLAIMS-MADE X X CUP-3X079407-25-NF 10/1/2025 10/1/2026 AGGREGATE $ 2,000,000 DED X RETENTION$ 0 $ B WORKERS COMPENSATION X PER STATUTE E ERR AND EMPLOYERS'LIABILITY WC 5646573-02 10/1/2025 10/1/2026 1,000,000 ANY PROPRIETOR/EXCLUDED? R/EXECUTIVE ❑ X E.L.EACH ACCIDENT $ OF EXCLUDED? N/A (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $ 1,000,000 If yes,describe under 1,000,000 DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ D Poll/Prof Liab. PECO06428602 10/1/2025 10/1/2026 $2Mill Occ/Agg: 3,000,000 DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached if more space is required) RE:Agreement:A-2022-025-02;Agreement To Provide On-Call Electrical Repair And Rehabilitation Services. glaiwv/auaiwv/wcwv/xsaiwv City of Santa Ana,its officers,employees,volunteers,agents and representatives and any other entity which contractor is required are included as Additional Insureds as respects General Liability,Auto Liability,and Umbrella Liability per attached endorsements. This Insurance shall apply as Primary and Non-Contributory per attached endorsement. Waiver of Subrogation for Workers'Compensation,General Liability,Auto Liability,and Umbrella Liability:See Attached Endorsements. *Excess Liability follows form over the General Liability,Auto Liability,and Employers Liability. APPROVED CERTIFICATE HOLDER By Tu Tran Nguyen at 4:27 pm,Sep 29,2025 CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE Digital ly signed THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN City of Santa Ana TU Trap byTuTran ACCORDANCE WITH THE POLICY PROVISIONS. 215 S.Center St.,M-85 Nguyen Santa Ana,CA 92701 Nguyen Date:2025.09.29 16:28:22-07'00' AUTHORIZED REPRESENTATIVE ACORD 25(2016/03) ©1988-2015 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD AGENCY CUSTOMER ID: LEEDELE-01 JLOPEZ LOC#: 1 ACORO ADDITIONAL REMARKS SCHEDULE Page 1 of 1 AGENCY NAMED INSURED Leed Commercial The Brokerage 1313a 1313 Electric,Inc. 8 Arctic Circle POLICY NUMBER Santa Fe Springs,CA 90670 SEE PAGE 1 CARRIER NAIC CODE SEE PAGE 1 SEE P 1 EFFECTIVE DATE:SEE PAGE 1 ADDITIONAL REMARKS THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM, FORM NUMBER: ACORD 25 FORM TITLE: Certificate of Liability Insurance Cancellation: *Should this policy be cancelled before the expiration date, The Brokerage, an Alera Group Company will mail 30(thirty) days written notice to those Certificate Holders which require such action per contract or agreement.* *Except 10 Days Notice of Cancellation for Non-Payment of Premium. ACORD 101 (2008/01) ©2008 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD POLICY NUMBER: A0230199003 COMMERCIAL GENERAL LIABILITY CG20101219 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - SCHEDULED PERSON OR ORGANIZATION This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name Of Additional Insured Person(s) Or Organization(s) Location(s) Of Covered Operations Any person or organization you are required to add as All locations per written contract, agreement, or permit. an additional insured under a written contract or agreement in effect prior to any accident, injury, loss Description: All jobs performed that have a written or damage. contract, agreement, or permit. Information required to complete this Schedule, if not shown above, will be shown in the Declarations. A. Section II - Who Is An Insured is amended to B. With respect to the insurance afforded to these include as an additional insured the person(s) or additional insureds, the following additional organization(s) shown in the Schedule, but only exclusions apply: with respect to liability for "bodily injury", This insurance does not apply to "bodily injury" or "property damage" or "personal and advertising "property damage" occurring after: injury" caused, in whole or in part, by: 1. All work, including materials, parts or 1. Your acts or omissions; or equipment furnished in connection with such 2. The acts or omissions of those acting on your work, on the project (other than service, behalf; maintenance or repairs) to be performed by or in the performance of your ongoing operations for on behalf of the additional insured(s) at the the additional insured(s) at the location(s) location of the covered operations has been designated above. completed; or However: 2. That portion of "your work" out of which the injury or damage arises has been put to its 1. The insurance afforded to such additional intended use by any person or organization insured only applies to the extent permitted by other than another contractor or law; and subcontractor engaged in performing 2. If coverage provided to the additional insured operations for a principal as a part of the same is required by a contract or agreement, the project. insurance afforded to such additional insured will not be broader than that which you are required by the contract or agreement to provide for such additional insured. CG 20 10 12 19 © Insurance Services Office, Inc., 2018 Page 1 of 2 Middlesex Insurance Company 1 00001 0000000000 24263 0 N a446f692-f058-488d-b503-ecae566ee9ec C. With respect to the insurance afforded to these 2. Available under the applicable limits of additional insureds, the following is added to insurance; Section III - Limits Of Insurance: whichever is less. If coverage provided to the additional insured is This endorsement shall not increase the required by a contract or agreement, the most we applicable limits of insurance. will pay on behalf of the additional insured is the amount of insurance: 1. Required by the contract or agreement; or Page 2 of 2 © Insurance Services Office, Inc., 2018 CG 20 10 12 19 Middlesex Insurance Company POLICY NUMBER: A0230199003 COMMERCIAL GENERAL LIABILITY CG20371219 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - COMPLETED OPERATIONS This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART SCHEDULE Name Of Additional Insured Person(s) Or Organization(s) Location And Description Of Completed Operations Any person or organization you are required to add as All locations and jobs performed that have a written an additional insured under a written contract or contract, agreement, or permit. agreement in effect prior to any accident, injury, loss or damage. Information required to complete this Schedule, if not shown above, will be shown in the Declarations. A. Section II - Who Is An Insured is amended to B. With respect to the insurance afforded to these include as an additional insured the person(s) or additional insureds, the following is added to organization(s) shown in the Schedule, but only Section III - Limits Of Insurance: with respect to liability for "bodily injury" or If coverage provided to the additional insured is "property damage" caused, in whole or in part, by required by a contract or agreement, the most we "your work" at the location designated and will pay on behalf of the additional insured is the described in the Schedule of this endorsement amount of insurance: performed for that additional insured and included in the "products-completed operations hazard". 1. Required by the contract or agreement; or However: 2. Available under the applicable limits of 1. The insurance afforded to such additional insurance; insured only applies to the extent permitted by whichever is less. law; and This endorsement shall not increase the 2. If coverage provided to the additional insured applicable limits of insurance. is required by a contract or agreement, the insurance afforded to such additional insured will not be broader than that which you are required by the contract or agreement to provide for such additional insured. CG 20 37 12 19 © Insurance Services Office, Inc., 2018 Page 1 of 1 Middlesex Insurance Company 1 00001 0000000000 24263 0 N 47fa9bb2-e8db-45fa-a04f-522cebOde319 POLICY NUMBER: A0230199003 COMMERCIAL GENERAL LIABILITY CG24041219 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US (WAIVER OF SUBROGATION) This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART ELECTRONIC DATA LIABILITY COVERAGE PART LIQUOR LIABILITY COVERAGE PART POLLUTION LIABILITY COVERAGE PART DESIGNATED SITES POLLUTION LIABILITY LIMITED COVERAGE PART DESIGNATED SITES PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART RAILROAD PROTECTIVE LIABILITY COVERAGE PART UNDERGROUND STORAGE TANK POLICY DESIGNATED TANKS SCHEDULE Name Of Person(s) Or Organization(s): Any person or organization from whom you are required to waive your right to recover under a written contract or agreement in effect prior to any loss or damage Information required to complete this Schedule, if not shown above, will be shown in the Declarations. The following is added to Paragraph 8. Transfer Of Rights Of Recovery Against Others To Us of Section IV- Conditions: We waive any right of recovery against the person(s) or organization(s) shown in the Schedule above because of payments we make under this Coverage Part. Such waiver by us applies only to the extent that the insured has waived its right of recovery against such person(s)or organization(s) prior to loss. This endorsement applies only to the person(s) or organization(s) shown in the Schedule above. Change effective 10/01/2024 CG 24 04 12 19 © Insurance Services Office, Inc., 2018 Page 1 of 1 A0230199 10/02/2024 Middlesex Insurance Company 1 00001 0000000000 24276 0 N 49482e82-36694497-8c96-6209611dd292 Coverage Extension Endorsement ZURICH THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. Policy No. BAP 4227795 -02 Effective Date: 10/01/2025 This endorsement modifies insurance provided under the: Business Auto Coverage Form Motor Carrier Coverage Form A. Amended Who Is An Insured 1. The following is added to the Who Is An Insured Provision in Section II—Covered Autos Liability Coverage: The following are also "insureds": a. Any "employee" of yours is an "insured" while using a covered "auto" you don't own, hire or borrow for acts performed within the scope of employment by you. Any"employee"of yours is also an "insured"while operating an "auto" hired or rented under a contract or agreement in an "employee's" name, with your permission, while performing duties related to the conduct of your business. b. Anyone volunteering services to you is an "insured"while using a covered "auto"you don't own, hire or borrow to transport your clients or other persons in activities necessary to your business. c. Anyone else who furnishes an "auto" referenced in Paragraphs A.1.a. and A.1.b. in this endorsement. d. Where and to the extent permitted by law, any person(s) or organization(s)where required by written contract or written agreement with you executed prior to any "accident", including those person(s) or organization(s) directing your work pursuant to such written contract or written agreement with you, provided the "accident" arises out of operations governed by such contract or agreement and only up to the limits required in the written contract or written agreement, or the Limits of Insurance shown in the Declarations, whichever is less. 2. The following is added to the Other Insurance Condition in the Business Auto Coverage Form and the Other Insurance— Primary and Excess Insurance Provisions Condition in the Motor Carrier Coverage Form: Coverage for any person(s) or organization(s), where required by written contract or written agreement with you executed prior to any "accident", will apply on a primary and non-contributory basis and any insurance maintained by the additional "insured" will apply on an excess basis. However, in no event will this coverage extend beyond the terms and conditions of the Coverage Form. B. Amendment—Supplementary Payments Paragraphs a.(2) and a.(4) of the Coverage Extensions Provision in Section II—Covered Autos Liability Coverage are replaced by the following: (2) Up to $5,000 for the cost of bail bonds (including bonds for related traffic law violations) required because of an "accident" we cover. We do not have to furnish these bonds. (4) All reasonable expenses incurred by the "insured"at our request, including actual loss of earnings up to $500 a day because of time off from work. C. Fellow Employee Coverage The Fellow Employee Exclusion contained in Section II—Covered Autos Liability Coverage does not apply. U-CA-424-H CW(10/21) Page 1 of 6 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. D. Driver Safety Program Liability and Physical Damage Coverage 1. The following is added to the Racing Exclusion in Section II—Covered Autos Liability Coverage: This exclusion does not apply to covered "autos" participating in a driver safety program event, such as, but not limited to, auto or truck rodeos and other auto or truck agility demonstrations. 2. The following is added to Paragraph 2. in B. Exclusions of Section III — Physical Damage Coverage of the Business Auto Coverage Form and Paragraph 2.b. in B. Exclusions of Section IV—Physical Damage Coverage of the Motor Carrier Coverage Form: This exclusion does not apply to covered "autos" participating in a driver safety program event, such as, but not limited to, auto or truck rodeos and other auto or truck agility demonstrations. E. Lease or Loan Gap Coverage The following is added to the Coverage Provision of the Physical Damage Coverage Section: Lease Or Loan Gap Coverage In the event of a total "loss"to a covered "auto", we will pay any unpaid amount due on the lease or loan for a covered "auto", less: a. Any amount paid under the Physical Damage Coverage Section of the Coverage Form; and b. Any: (1) Overdue lease or loan payments at the time of the "loss"; (2) Financial penalties imposed under a lease for excessive use, abnormal wear and tear or high mileage; (3) Security deposits not returned by the lessor; (4) Costs for extended warranties, credit life insurance, health, accident or disability insurance purchased with the loan or lease; and (5) Carry-over balances from previous leases or loans. F. Towing and Labor Paragraph A.2. of the Physical Damage Coverage Section is replaced by the following: We will pay up to $75 for towing and labor costs incurred each time a covered "auto"that is a "private passenger type", light truck or medium truck is disabled. However, the labor must be performed at the place of disablement. As used in this provision, "private passenger type"means a private passenger or station wagon type"auto"and includes an "auto" of the pickup or van type if not used for business purposes. G. Extended Glass Coverage The following is added to Paragraph A.3.a. of the Physical Damage Coverage Section: If glass must be replaced, the deductible shown in the Declarations will apply. However, if glass can be repaired and is actually repaired rather than replaced,the deductible will be waived. You have the option of having the glass repaired rather than replaced. H. Hired Auto Physical Damage— Increased Loss of Use Expenses The Coverage Extension for Loss Of Use Expenses in the Physical Damage Coverage Section is replaced by the following: Loss Of Use Expenses For Hired Auto Physical Damage, we will pay expenses for which an "insured" becomes legally responsible to pay for loss of use of a vehicle rented or hired without a driver under a written rental contract or written rental agreement. We will pay for loss of use expenses if caused by: (1) Other than collision only if the Declarations indicate that Comprehensive Coverage is provided for any covered "auto"; U-CA-424-H CW(10/21) Page 2 of 6 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. (2) Specified Causes Of Loss only if the Declarations indicate that Specified Causes Of Loss Coverage is provided for any covered "auto"; or (3) Collision only if the Declarations indicate that Collision Coverage is provided for any covered "auto". However, the most we will pay for any expenses for loss of use is $100 per day, to a maximum of$3000. I. Personal Effects Coverage The following is added to the Coverage Provision of the Physical Damage Coverage Section: Personal Effects Coverage a. We will pay up to $750 for"loss" to personal effects which are: (1) Personal property owned by an "insured"; and (2) In or on a covered "auto". b. Subject to Paragraph a. above, the amount to be paid for"loss"to personal effects will be based on the lesser of: (1) The reasonable cost to replace; or (2) The actual cash value. c. The coverage provided in Paragraphs a. and b. above, only applies in the event of a total theft of a covered "auto". No deductible applies to this coverage. However,we will not pay for"loss"to personal effects of any of the following: (1) Accounts, bills, currency, deeds, evidence of debt, money, notes, securities, or commercial paper or other documents of value. (2) Bullion, gold, silver, platinum,or other precious alloys or metals; furs or fur garments;jewelry,watches, precious or semi-precious stones. (3) Paintings, statuary and other works of art. (4) Contraband or property in the course of illegal transportation or trade. (5) Tapes, records, discs or other similar devices used with audio, visual or data electronic equipment. Any coverage provided by this Provision is excess over any other insurance coverage available for the same "loss". J. Tapes, Records and Discs Coverage 1. The Exclusion in Paragraph B.4.a. of Section III — Physical Damage Coverage in the Business Auto Coverage Form and the Exclusion in Paragraph B.2.c. of Section IV — Physical Damage Coverage in the Motor Carrier Coverage Form does not apply. 2. The following is added to Paragraph 1.a.Comprehensive Coverage under the Coverage Provision of the Physical Damage Coverage Section: We will pay for 'loss" to tapes, records, discs or other similar devices used with audio, visual or data electronic equipment. We will pay only if the tapes, records, discs or other similar audio, visual or data electronic devices: (a) Are the property of an "insured"; and (b) Are in a covered "auto" at the time of"loss". The most we will pay for such"loss"to tapes, records, discs or other similar devices is$500. The Physical Damage Coverage Deductible Provision does not apply to such 'loss". K. Airbag Coverage The Exclusion in Paragraph B.3.a. of Section III— Physical Damage Coverage in the Business Auto Coverage Form and the Exclusion in Paragraph B.4.a. of Section IV — Physical Damage Coverage in the Motor Carrier Coverage Form does not apply to the accidental discharge of an airbag. L. Two or More Deductibles The following is added to the Deductible Provision of the Physical Damage Coverage Section: U-CA-424-H CW(10/21) Page 3 of 6 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. If an accident is covered both by this policy or Coverage Form and by another policy or Coverage Form issued to you by us, the following applies for each covered "auto" on a per vehicle basis: 1. If the deductible on this policy or Coverage Form is the smaller (or smallest) deductible, it will be waived; or 2. If the deductible on this policy or Coverage Form is not the smaller(or smallest)deductible, it will be reduced by the amount of the smaller(or smallest) deductible. M. Temporary Substitute Autos— Physical Damage 1. The following is added to Section I —Covered Autos: Temporary Substitute Autos— Physical Damage If Physical Damage Coverage is provided by this Coverage Form on your owned covered "autos", the following types of vehicles are also covered "autos" for Physical Damage Coverage: Any "auto" you do not own when used with the permission of its owner as a temporary substitute for a covered "auto"you do own but is out of service because of its: 1. Breakdown; 2. Repair; 3. Servicing; 4. "Loss"; or 5. Destruction. 2. The following is added to the Paragraph A. Coverage Provision of the Physical Damage Coverage Section: Temporary Substitute Autos—Physical Damage We will pay the owner for"loss" to the temporary substitute "auto" unless the "loss" results from fraudulent acts or omissions on your part. If we make any payment to the owner, we will obtain the owner's rights against any other party. The deductible for the temporary substitute "auto" will be the same as the deductible for the covered "auto" it replaces. N. Amended Duties In The Event Of Accident, Claim, Suit Or Loss Paragraph a. of the Duties In The Event Of Accident, Claim, Suit Or Loss Condition is replaced by the following: a. In the event of"accident", claim, "suit" or"loss", you must give us or our authorized representative prompt notice of the "accident", claim, "suit" or "loss". However, these duties only apply when the "accident", claim, "suit" or "loss" is known to you (if you are an individual), a partner(if you are a partnership), a member (if you are a limited liability company) or an executive officer or insurance manager(if you are a corporation). The failure of any agent, servant or employee of the "insured" to notify us of any "accident", claim, "suit" or "loss" shall not invalidate the insurance afforded by this policy. Include, as soon as practicable: (1) How,when and where the "accident"or"loss"occurred and if a claim is made or"suit" is brought, written notice of the claim or"suit" including, but not limited to, the date and details of such claim or"suit"; (2) The "insured's" name and address; and (3) To the extent possible, the names and addresses of any injured persons and witnesses. If you report an "accident", claim, "suit"or"loss"to another insurer when you should have reported to us,your failure to report to us will not be seen as a violation of these amended duties provided you give us notice as soon as practicable after the fact of the delay becomes known to you. O. Waiver of Transfer Of Rights Of Recovery Against Others To Us The following is added to the Transfer Of Rights Of Recovery Against Others To Us Condition: U-CA-424-H CW(10/21) Page 4 of 6 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. This Condition does not apply to the extent required of you by a written contract, executed prior to any "accident" or "loss", provided that the "accident" or "loss" arises out of operations contemplated by such contract. This waiver only applies to the person or organization designated in the contract. P. Employee Hired Autos— Physical Damage Paragraph b. of the Other Insurance Condition in the Business Auto Coverage Form and Paragraph f. of the Other Insurance— Primary and Excess Insurance Provisions Condition in the Motor Carrier Coverage Form are replaced by the following: For Hired Auto Physical Damage Coverage, the following are deemed to be covered "autos" you own: (1) Any covered "auto" you lease, hire, rent or borrow; and (2) Any covered "auto" hired or rented under a written contract or written agreement entered into by an "employee" or elected or appointed official with your permission while being operated within the course and scope of that "employee's" employment by you or that elected or appointed official's duties as respect their obligations to you. However, any"auto" that is leased, hired, rented or borrowed with a driver is not a covered "auto". Q. Unintentional Failure to Disclose Hazards The following is added to the Concealment, Misrepresentation Or Fraud Condition: However, we will not deny coverage under this Coverage Form if you unintentionally: (1) Fail to disclose any hazards existing at the inception date of this Coverage Form; or (2) Make an error, omission, improper description of"autos" or other misstatement of information. You must notify us as soon as possible after the discovery of any hazards or any other information that was not provided to us prior to the acceptance of this policy. R. Hired Auto—World Wide Coverage Paragraph 7.b.(5) of the Policy Period, Coverage Territory Condition is replaced by the following: (5) Anywhere else in the world if a covered "auto" is leased, hired, rented or borrowed for a period of 60 days or less, S. Bodily Injury Redefined The definition of"bodily injury" in the Definitions Section is replaced by the following: "Bodily injury" means bodily injury, sickness or disease, sustained by a person including death or mental anguish, resulting from any of these at any time. Mental anguish means any type of mental or emotional illness or disease. T. Expected Or Intended Injury The Expected Or Intended Injury Exclusion in Paragraph B. Exclusions under Section II —Covered Auto Liability Coverage is replaced by the following: Expected Or Intended Injury "Bodily injury"or"property damage"expected or intended from the standpoint of the "insured". This exclusion does not apply to "bodily injury" or"property damage" resulting from the use of reasonable force to protect persons or property. U. Physical Damage—Additional Temporary Transportation Expense Coverage Paragraph AA.a. of Section III— Physical Damage Coverage is replaced by the following: 4. Coverage Extensions a. Transportation Expenses We will pay up to $50 per day to a maximum of$1,000 for temporary transportation expense incurred by you because of the total theft of a covered "auto" of the private passenger type. We will pay only for those covered "autos" for which you carry either Comprehensive or Specified Causes of Loss Coverage. We will pay for temporary transportation expenses incurred during the period beginning 48 hours after the theft and ending, regardless of the policy's expiration, when the covered "auto" is returned to use or we pay for its "loss". U-CA-424-H CW(10/21) Page 5 of 6 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. V. Replacement of a Private Passenger Auto with a Hybrid or Alternative Fuel Source Auto The following is added to Paragraph A. Coverage of the Physical Damage Coverage Section: In the event of a total "loss" to a covered "auto" of the private passenger type that is replaced with a hybrid "auto" or "auto" powered by an alternative fuel source of the private passenger type, we will pay an additional 10% of the cost of the replacement"auto", excluding tax, title, license, other fees and any aftermarket vehicle upgrades, up to a maximum of$2500. The covered "auto" must be replaced by a hybrid "auto" or an "auto" powered by an alternative fuel source within 60 calendar days of the payment of the "loss" and evidenced by a bill of sale or new vehicle lease agreement. To qualify as a hybrid "auto", the "auto" must be powered by a conventional gasoline engine and another source of propulsion power. The other source of propulsion power must be electric, hydrogen, propane, solar or natural gas, either compressed or liquefied. To qualify as an "auto" powered by an alternative fuel source, the "auto" must be powered by a source of propulsion power other than a conventional gasoline engine. An "auto" solely propelled by biofuel, gasoline or diesel fuel or any blend thereof is not an "auto" powered by an alternative fuel source. W. Return of Stolen Automobile The following is added to the Coverage Extension Provision of the Physical Damage Coverage Section: If a covered "auto" is stolen and recovered, we will pay the cost of transport to return the "auto"to you. We will pay only for those covered "autos" for which you carry either Comprehensive or Specified Causes of Loss Coverage. All other terms, conditions, provisions and exclusions of this policy remain the same. U-CA-424-H CW(10/21) Page 6 of 6 Includes copyrighted material of Insurance Services Office, Inc.,with its permission. WORKERS' COMPENSATION AND EMPLOYERS' LIABILITY INSURANCE POLICY WC 0❑03 0❑1111d. ❑1111❑❑ WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT- CALIFORNIA This endorsement changes the policy to which it is attached effective on the inception date of the policy unless a different date is indicated below. the following -attaching clause-need be completed only when this endorsement is issued subsequent to preparation of the policy.- This endorsement, effective on 10/01/2025 at 12:01 A.M. standard time, forms a part of DAT-- Policy ❑o. WC 5646573 -02 ❑ndorsement ❑o. of the Zurich American Insurance Company CAME]OF IDSORADCD COMPA-Y- issued to Leed Electric, Inc. Premium if any-- Authorized Representative We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule. :This agreement applies only to the event that you perform wor❑under a written contract that requires you to obtain this agreement from us.— You must maintain payroll records accurately segregating the remuneration of your employees while engaged in the wor❑described in the Schedule. The additional premium for this endorsement shall be ❑ of the California worEOrs❑compensation pre[] mium otherwise due on such remuneration. Schedule Person or Organization Job Description ALL P❑RSO❑S A❑DOOR ALL CA OP❑RATIO❑S ORGA❑IZATIO❑S THAT AR❑ R❑Q❑IR❑D BY WRITT❑❑ CO❑TRACT OR AGR❑❑M❑❑T WITH TH❑ 111S❑R❑D, ❑❑❑C❑T❑D PRIOR TO TH❑ACCID❑❑T OR LOSS, THAT WAIV❑R OF S❑BROGATIO❑ B❑ PROVID❑D ❑❑D❑R THIS POLICY FOR WORD P❑RFORM❑D BY YO❑ FOR THAT P❑RSO❑A❑DOOR ORGA❑IZATIO❑ WC 2E2 1111mo WC 01103 0❑mod. 0=0 Page 1 of 1 One Tower Sauare, Hartford, Connecticut 06183 POLICY DECLARATIONS EXCESS FOLLOW-FORM AND UMBRELLA POLICY NO.: CUP-3X079407-25-NF LIABILITY INSURANCE POLICY ISSUE DATE: 9/26/2025 INSURING COMPANY:TRAVELERS PROPERTY CASUALTY COMPANY OF AMERICA 1. NAMED INSURED AND MAILING ADDRESS: LEED ELECTRIC, INC. 13138 ARCTIC CIRCLE SANTA FE SPRINGS CA 90670 2. POLICY PERIOD: From 10/01/2025 to 10/01/2026 12:01 A.M. Standard Time at your mailing address. 3. LIMITS OF INSURANCE: COVERAGES LIMITS OF LIABILITY AGGREGATE LIMITS OF LIABILITY $15,000,000 General Aggregate $15,000,000 Products-Completed Operations Aggregate EXCESS FOLLOW-FORM AND $15,000,000 Occurrence Limit UMBRELLA LIABILITY CRISIS MANAGEMENT SERVICE $150,000 all Crisis Management Events EXPENSES 4. SELF-INSURED RETENTION: $10,000 any one occurrence or event 5. PREMIUM: $ 6. TAXES AND SURCHARGES: 7. On the effective date shown in Item 2., the Excess Follow-Form And Umbrella Liability Insurance Policy numbered above includes this Declarations Page and any forms and endorsements shown on the Listing Of Forms, Endorsements And Schedule Numbers. 8. If the Schedule Of Underlying Insurance includes any coverage provided on a claims-made basis, then the following disclaimer applies. COVERAGE WILL APPLY ON A CLAIMS-MADE BASIS WHEN FOLLOWING CLAIMS-MADE UNDERLYING INSURANCE. 9. If the Schedule Of Underlying Insurance includes any coverage which includes defense expenses within the limits of liability, then the following disclaimer applies: DEFENSE EXPENSES ARE PAYABLE WITHIN, AND ARE NOT IN ADDITION TO, THE LIMITS OF INSURANCE WITH RESPECT TO SOME OR ALL OF THE COVERAGES PROVIDED. NAME AND ADDRESS OF AGENT OR BROKER: COUNTERSIGNED BY: ALERA-ORION RISK MGMT - DKL94 18575 Jamboree Road, Suite 500 Irvine, CA 92 612 Authorized Representative DATE: OFFICE: SP-LOS ANGELES EU 00 02 09 20 ©2019 The Travelers Indemnity Company.All rights reserved. Page 1 of 1 UMBRELLA POLICY NUMBER: CUP-3X079407-25-NF ISSUE DATE: 9/26/2025 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. SCHEDULE OF UNDERLYING INSURANCE This endorsement modifies insurance provided under the following: EXCESS FOLLOW-FORM AND UMBRELLA LIABILITY INSURANCE Employers Liability Limits Of Liability CarrlerZURICH AMERICAN INSURANCE Bodily Injury By Accident $1,000,000* COMPANY Each Accident Policy Number WC 5646573 - 02 Bodily Injury By Disease $1,000,000* Policy Limit Policy Period From: 10/01/2025 Bodily Injury By Disease $1,000,000* Each Employee to: 10/01/2026 *UNLIMITED IN THE STATE OF NEW YORK FOR SUBJECT EMPLOYEES Automobile Liability Limits Of Liability CarrlerZURICH AMERICAN INSURANCE Bodily Injury And Property $1,000,000 COMPANY Damage Combined Single Limit Policy Number BAP 4227795 - 02 Policy Period From: 10/01/2025 to: 10/01/2026 Commercial General Liability Limits Of Liability Carrier MIDDLESEX INSURANCE COMPANY General Aggregate $3,000,000 Products-Completed $2,000,000 Policy Number A0230199003 Operations Aggregate Policy Period Personal and Advertising Injury $1,000,000 From: 10/01/2025 to: 10/01/2026 Each Occurrence $1,000,000 PRODUCER:ALERA-ORION RISK MGMT OFFICE:SP-LOS ANGELES 08L EU 00 03 08 18 ©2018 The Travelers Indemnity Company.All rights reserved. Page 1 of 1