Laserfiche WebLink
I <br /> EXHIBIT 2 <br /> regardless of source of manufacture or construction;assign and schedule work at their discretion; <br /> and <br /> (l) Assign overtone, determine when it will be worked and the number aixd identity of I <br /> employees engaged in such work, subject to such provisions in the applicable Master Tabor <br /> Agreement (s)requiring such assignments be equalized or otherwise made in a nondiscriminatory <br /> manner. <br /> Section 9.2 Specific City Rights In addition to the following and other rights of the City <br /> enumerated in this Agreement,the City expressly reserves its management rights and all the rights <br /> conferred on it by law. The City's rights (and those of the Contract Administrator on its behalf) <br /> include but are not limited to the right to: <br /> (a) Inspect any construction site or facility to ensure that the Contractor follows the <br /> applicable safety and other work requirements; l <br /> (b) Require Contractors to establish a different work week or shift schedule for <br /> particular employees as required to meet the operational needs of the Project Work at a particular <br /> location; <br /> i <br /> (c) At its sole option, terminate, delay and/or suspend any and all portions of the <br /> covered work at any time;prohibit some or all work on certain days or during certain hours of the <br /> day to accommodate the ongoing operations of the City's Facilities arid/or to mitigate the effect of <br /> ongoing Project Work on businesses and residents in the neighborhood of the Project site; and/or <br /> require such other operational or schedule changes it deeYns necessary, in its sole judgment, to <br /> effectively maintain its primary mission and remain a good neighbor to those in the area of its <br /> facilities. (In order to permit the Contractors and Unions to make appropriate scheduling plans,the <br /> City will provide the CWA Administrator, and the affected Contractor(s) and Union(s) with <br /> reasonable notice of any changes it requires pursuant to this section; provided, however, that if <br /> notice is not provided in time to advise employees not to report for work, show-up pay shall be <br /> due pursuant to the provision of Article 6, Section 6.6); <br /> (d) Approve any work methods, procedures and techniques used by Contractors <br /> whether or not these methods, procedures or techniques are part of industry practices or customs; <br /> and <br /> (e) Investigate and process complaints, through the CWA Administrator, in the matter <br /> set forth in Articles 7 and 10. <br /> Section 9.3 Use of Materials There should be no limitations or restriction by Union upon <br /> a Contractor's choice of materials or design, not, regardless of source or location, upon the frill <br /> use and utilization, of equipment, machinery, packaging, precast, prefabricated, prefinished, or k <br /> preassernbled materials, tools or other labor saving devices, subject to the application of the State <br /> Public Contracts and Labor Codes as required by law.The onsite installation or application of such <br /> items shall be performed by the craft having jurisdiction over such work. <br /> 3 <br /> i <br /> Community Workforce Agreement 22 City of Santa Ana <br />